AB621-ASA2,15,21 (b) The department or the contracting local governmental unit may demand and examine, and every contractor, subcontractor, and contractor's or subcontractor's agent shall keep, and furnish upon request by the department or local governmental unit, copies of payrolls and other records and information relating to the wages paid to individuals performing the work described in sub. (4) for work to which this section applies. The department may inspect records in the manner provided in ch. 103. Every contractor, subcontractor, or agent performing work on a project of public works that is subject to this section is subject to the requirements of ch. 103 relating to the examination of records.

AB621-ASA2,16,10 (c) If requested by any person, the department shall inspect the payroll records of any contractor, subcontractor, or agent performing work on a project of public works that is subject to this section as provided in this paragraph to ensure compliance with this section. On receipt of such a request, the department shall request that the contractor, subcontractor, or agent submit to the department a certified record of the information specified in par. (a), other than personally identifiable information relating to an employee of the contractor, subcontractor, or agent, for no longer than a 4-week period. The department may request that a contractor, subcontractor, or agent submit those records no more than once per calendar quarter for each project of public works on which the contractor, subcontractor, or agent is performing work. The department may not charge a requester a fee for obtaining that information. Certified records submitted to the department under this paragraph are open for public inspection and copying under s. 19.35 (1).

AB621-ASA2,16,16 (d) Section 103.005 (5) (f), (11), (12), and (13) applies to this section, except that s. 103.005 (12) (a) does not apply to a person who fails to provide any information to the department to assist the department in determining prevailing wage rates under sub. (3) (am) or (ar). Section 111.322 (2m) applies to discharge and other discriminatory acts arising in connection with any proceeding under this section, including proceedings under sub. (11) (a).

AB621-ASA2,16,23 (11) Liability and penalties. (a) 1. A contractor, subcontractor, or contractor's or subcontractor's agent who fails to pay the prevailing wage rate determined by the department under sub. (3) or who pays less than 1.5 times the hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor is liable to any affected employee in the amount of his or her unpaid wages or his or her unpaid overtime compensation and in an additional amount as liquidated damages as provided under subd. 2. or 3., whichever is applicable.

AB621-ASA2,17,7 2. If the department determines upon inspection under sub. (10) (b) or (c) that a contractor, subcontractor, or contractor's or subcontractor's agent has failed to pay the prevailing wage rate determined by the department under sub. (3) or has paid less than 1.5 times the hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor, the department shall order the contractor to pay to any affected employee the amount of his or her unpaid wages or his or her unpaid overtime compensation and an additional amount equal to 100 percent of the amount of those unpaid wages or that unpaid overtime compensation as liquidated damages within a period specified by the department in the order.

AB621-ASA2,17,18 3. In addition to or in lieu of recovering the liability specified in subd. 1. as provided in subd. 2., any employee for and on behalf of that employee and other employees similarly situated may commence an action to recover that liability in any court of competent jurisdiction. If the court finds that a contractor, subcontractor, or contractor's or subcontractor's agent has failed to pay the prevailing wage rate determined by the department under sub. (3) or has paid less than 1.5 times the hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor, the court shall order the contractor, subcontractor, or agent to pay to any affected employee the amount of his or her unpaid wages or his or her unpaid overtime compensation and an additional amount equal to 100 percent of the amount of those unpaid wages or that unpaid overtime compensation as liquidated damages.

AB621-ASA2,17,23 5. No employee may be a party plaintiff to an action under subd. 3. unless the employee consents in writing to become a party and the consent is filed in the court in which the action is brought. Notwithstanding s. 814.04 (1), the court shall, in addition to any judgment awarded to the plaintiff, allow reasonable attorney fees and costs to be paid by the defendant.

AB621-ASA2,18,2 (b) 1. Except as provided in subds. 2., 4., and 6., any contractor, subcontractor, or contractor's or subcontractor's agent who violates this section may be fined not more than $200 or imprisoned for not more than 6 months or both. Each day that any violation continues is a separate offense.

AB621-ASA2,18,11 2. Whoever induces any individual who seeks to be or is employed on any project of public works that is subject to this section to give up, waive, or return any part of the wages to which the individual is entitled under the contract governing the project, or who reduces the hourly basic rate of pay normally paid to an individual for work on a project that is not subject to this section during a week in which the individual works both on a project of public works that is subject to this section and on a project that is not subject to this section, by threat not to employ, by threat of dismissal from employment, or by any other means is guilty of an offense under s. 946.15 (1).

AB621-ASA2,18,21 3. Any individual employed on a project of public works that is subject to this section who knowingly allows a contractor, subcontractor, or contractor's or subcontractor's agent to pay him or her less than the prevailing wage rate set forth in the contract governing the project, who gives up, waives, or returns any part of the compensation to which he or she is entitled under the contract, or who gives up, waives, or returns any part of the compensation to which he or she is normally entitled for work on a project that is not subject to this section during a week in which the individual works both on a project of public works that is subject to this section and on a project that is not subject to this section, is guilty of an offense under s. 946.15 (2).

AB621-ASA2,19,2 4. Whoever induces any individual who seeks to be or is employed on any project of public works that is subject to this section to allow any part of the wages to which the individual is entitled under the contract governing the project to be deducted from the individual's pay is guilty of an offense under s. 946.15 (3), unless the deduction would be allowed under 29 CFR 3.5 or 3.6 from an individual who is working on a project that is subject to 40 USC 3142.

AB621-ASA2,19,8 5. Any individual who is employed on a project of public works that is subject to this section who knowingly allows any part of the wages to which he or she is entitled under the contract governing the project to be deducted from his or her pay is guilty of an offense under s. 946.15 (4), unless the deduction would be allowed under 29 CFR 3.5 or 3.6 from an individual who is working on a project that is subject to 40 USC 3142.

AB621-ASA2,19,11 6. Subdivision 1. does not apply to any person who fails to provide any information to the department to assist the department in determining prevailing wage rates under sub. (3) (am) or (ar).

AB621-ASA2,19,24 (12) Debarment. (a) Except as provided under pars. (b) and (c), the department shall notify any local governmental unit applying for a determination under sub. (3) of the names of all persons that the department has found to have failed to pay the prevailing wage rate determined under sub. (3) or has found to have paid less than 1.5 times the hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor at any time in the preceding 3 years. The department shall include with each name the address of the person and shall specify when the person failed to pay the prevailing wage rate and when the person paid less than 1.5 times the hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor. A local governmental unit may not award any contract to the person unless otherwise recommended by the department or unless 3 years have elapsed from the date the department issued its findings or the date of final determination by a court of competent jurisdiction, whichever is later.

AB621-ASA2,20,6 (b) The department may not include in a notification under par. (a) the name of any person on the basis of having subcontracted a contract for a project of public works to a person that the department has found to have failed to pay the prevailing wage rate determined under sub. (3) or has found to have paid less than 1.5 times the hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor.

AB621-ASA2,20,10 (c) This subsection does not apply to any contractor, subcontractor, or agent who in good faith commits a minor violation of this section, as determined on a case-by-case basis through administrative hearings with all rights to due process afforded to all parties or who has not exhausted or waived all appeals.

AB621-ASA2,20,20 (d) Any person submitting a bid or negotiating a contract on a project of public works that is subject to this section shall, on the date the person submits the bid or negotiates the contract, identify any construction business in which the person, or a shareholder, officer, or partner of the person, if the person is a business, owns, or has owned at least a 25 percent interest on the date the person submits the bid or negotiates the contract or at any other time within 3 years preceding the date the person submits the bid or negotiates the contract, if the business has been found to have failed to pay the prevailing wage rate determined under sub. (3) or to have paid less than 1.5 times the hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor.

AB621-ASA2,20,21 (e) The department shall promulgate rules to administer this subsection.

AB621-ASA2,17 Section 17 . 84.41 (3) of the statutes is created to read:

AB621-ASA2,21,2 84.41 (3) Employment regulations. Employment regulations set forth in s. 103.50 pertaining to wages and hours shall apply to all projects constructed under s. 84.40 in the same manner as such laws apply to projects on other state highways. Where applicable, the federal wages and hours law known as the Davis-Bacon act shall apply.

AB621-ASA2,18 Section 18 . 84.54 of the statutes is repealed.

AB621-ASA2,19 Section 19 . 86.51 of the statutes is repealed.

AB621-ASA2,20 Section 20 . 103.005 (12) (a) of the statutes is amended to read:

AB621-ASA2,21,16 103.005 (12) (a) If any employer, employee, owner, or other person violates chs. 103 to 106, or fails or refuses to perform any duty required under chs. 103 to 106, within the time prescribed by the department, for which no penalty has been specifically provided, or fails, neglects or refuses to obey any lawful order given or made by the department or any judgment or decree made by any court in connection with chs. 103 to 106, for each such violation, failure or refusal, the employer, employee, owner or other person shall forfeit not less than $10 nor more than $100 for each offense. This paragraph does not apply to any person that fails to provide any information to the department to assist the department in determining prevailing wage rates or prevailing hours of labor under s. 103.49 (3) (a) or (am) or 103.50 (3) or (4).

AB621-ASA2,21 Section 21 . 103.49 of the statutes is created to read:

AB621-ASA2,21,18 103.49 Wage rate on state work. (1) Definitions. In this section:

AB621-ASA2,22,2 (a) “Area" means the county in which a proposed project of public works that is subject to this section is located or, if the department determines that there is insufficient wage data in that county, “area" means those counties that are contiguous to that county or, if the department determines that there is insufficient wage data in those counties, “area" means those counties that are contiguous to those counties or, if the department determines that there is insufficient wage data in those counties, “area" means the entire state or, if the department is requested to review a determination under sub. (3) (c), “area" means the city, village, or town in which a proposed project of public works that is subject to this section is located.

AB621-ASA2,22,8 (am) “Bona fide economic benefit" means an economic benefit for which an employer makes irrevocable contributions to a trust or fund created under 29 USC 186 (c) or to any other bona fide plan, trust, program, or fund no less often than quarterly or, if an employer makes annual contributions to such a bona fide plan, trust, program, or fund, for which the employer irrevocably escrows moneys at least quarterly based on the employer's expected annual contribution.

AB621-ASA2,22,12 (b) “Hourly basic rate of pay" means the hourly wage paid to any employee, excluding any contributions or payments for health insurance benefits, vacation benefits, pension benefits, and any other bona fide economic benefits, whether paid directly or indirectly.