Amendment SA2-AB748

AB748-SA2,108,2 (ar) In determining prevailing wage rates under par. (a) or (am), the department may not use data from projects that are subject to this section, s. 66.0903, 103.50, or 229.8275, or 40 USC 3142 unless the department determines that there is insufficient wage data in the area to determine those prevailing wage rates, in which case the department may use data from projects that are subject to this section, s. 66.0903, 103.50, or 229.8275, or 40 USC 3142. In determining prevailing wage rates under par. (a) or (am), the department may not use data from any construction work performed by a state agency or a local governmental unit, as defined in s. 66.0903 (1) (d).

AB748-SA2,108,11 (b) Any person may request a recalculation of any portion of an initial determination within 30 days after the initial determination date if the person submits evidence with the request showing that the prevailing wage rate for any given trade or occupation included in the initial determination does not represent the prevailing wage rate for that trade or occupation in the area. The evidence shall include wage rate information reflecting work performed by persons working in the contested trade or occupation in the area during the current survey period. The department shall affirm or modify the initial determination within 15 days after the date on which the department receives the request for recalculation.

AB748-SA2,108,25 (c) In addition to the recalculation under par. (b), the state agency that requested the determination under this subsection may request a review of any portion of a determination within 30 days after the date of issuance of the determination if the state agency submits evidence with the request showing that the prevailing wage rate for any given trade or occupation included in the determination does not represent the prevailing wage rate for that trade or occupation in the city, village, or town in which the proposed project of public works is located. That evidence shall include wage rate information for the contested trade or occupation on at least 3 similar projects located in the city, village, or town where the proposed project of public works is located on which some work has been performed during the current survey period and that were considered by the department in issuing its most recent compilation under par. (am). The department shall affirm or modify the determination within 15 days after the date on which the department receives the request for review.

AB748-SA2,109,1 (3g) Nonapplicability. This section does not apply to any of the following:

AB748-SA2,109,4 (a) A single-trade project of public works for which the estimated project cost of completion is less than $48,000 or a multiple-trade project of public works for which the estimated project cost of completion is less than $100,000.

AB748-SA2,109,8 (b) Work performed on a project of public works for which the state or the state agency contracting for the project is not required to compensate any contractor, subcontractor, contractor's or subcontractor's agent, or individual for performing the work.

AB748-SA2,109,10 (c) Minor service or maintenance work, warranty work, or work under a supply and installation contract.

AB748-SA2,109,11 (f) A public highway, street, or bridge project.

AB748-SA2,109,14 (g) A project of public works involving the erection, construction, repair, remodeling, or demolition of a residential property containing 2 dwelling units or less.

AB748-SA2,109,19 (h) A road, street, bridge, sanitary sewer, or water main project that is a part of a development in which not less than 90 percent of the lots contain or will contain 2 dwelling units or less, as determined by the local governmental unit at the time of approval of the development, and that, on completion, is acquired by, or dedicated to, the state for ownership or maintenance by the state.

AB748-SA2,110,2 (4r) Compliance. (a) When the department finds that a state agency has not requested a determination under sub. (3) (a) or that a state agency, contractor, or subcontractor has not physically incorporated a determination into a contract or subcontract as required under sub. (2) or has not notified a minor subcontractor of a determination in the manner prescribed by the department by rule promulgated under sub. (2), the department shall notify the state agency, contractor or subcontractor of the noncompliance and shall file the determination with the state agency, contractor, or subcontractor within 30 days after such notice.

AB748-SA2,110,7 (b) Upon completion of a project of public works and before receiving final payment for his or her work on the project, each agent or subcontractor shall furnish the contractor with an affidavit stating that the agent or subcontractor has complied fully with the requirements of this section. A contractor may not authorize final payment until the affidavit is filed in proper form and order.

AB748-SA2,110,21 (c) Upon completion of a project of public works and before receiving final payment for his or her work on the project, each contractor shall file with the state agency authorizing the work an affidavit stating that the contractor has complied fully with the requirements of this section and that the contractor has received an affidavit under par. (b) from each of the contractor's agents and subcontractors. A state agency may not authorize a final payment until the affidavit is filed in proper form and order. If a state agency authorizes a final payment before an affidavit is filed in proper form and order or if the department determines, based on the greater weight of the credible evidence, that any person performing the work specified in sub. (2m) has been or may have been paid less than the prevailing wage rate or less than 1.5 times the hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor and requests that the state agency withhold all or part of the final payment, but the state agency fails to do so, the state agency is liable for all back wages payable up to the amount of the final payment.

AB748-SA2,111,2 (5) Records; inspection; enforcement. (a) Each contractor, subcontractor, or contractor's or subcontractor's agent performing work on a project of public works that is subject to this section shall keep full and accurate records clearly indicating the name and trade or occupation of every person performing the work described in sub. (2m) and an accurate record of the number of hours worked by each of those persons and the actual wages paid for the hours worked.

AB748-SA2,111,13 (b) It shall be the duty of the department to enforce this section. To this end it may demand and examine, and every contractor, subcontractor, and contractor's and subcontractor's agent shall keep, and furnish upon request by the department, copies of payrolls and other records and information relating to the wages paid to persons performing the work described in sub. (2m) for work to which this section applies. The department may inspect records in the manner provided in this chapter. Every contractor, subcontractor, or agent performing work on a project of public works that is subject to this section is subject to the requirements of this chapter relating to the examination of records. Section 111.322 (2m) applies to discharge and other discriminatory acts arising in connection with any proceeding under this section.

AB748-SA2,112,2 (c) If requested by any person, the department shall inspect the payroll records of any contractor, subcontractor, or agent performing work on a project of public works that is subject to this section as provided in this paragraph to ensure compliance with this section. On receipt of such a request, the department shall request the contractor, subcontractor, or agent to submit to the department a certified record of the information specified in par. (a), other than personally identifiable information relating to an employee of the contractor, subcontractor, or agent, for no longer than a 4-week period. The department may request a contractor, subcontractor, or agent to submit those records no more than once per calendar quarter for each project of public works on which the contractor, subcontractor, or agent is performing work. The department may not charge a requester a fee for obtaining that information. The department shall make available for public inspection certified records submitted to the department under this paragraph.

AB748-SA2,112,9 (6m) Liability and penalties. (ag) 1. Any contractor, subcontractor, or contractor's or subcontractor's agent who fails to pay the prevailing wage rate determined by the department under sub. (3) or who pays less than 1.5 times the hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor is liable to any affected employee in the amount of his or her unpaid wages or his or her unpaid overtime compensation and in an additional amount as liquidated damages as provided in subd. 2. or 3., whichever is applicable.

AB748-SA2,112,18 2. If the department determines upon inspection under sub. (5) (b) or (c) that a contractor, subcontractor, or contractor's or subcontractor's agent has failed to pay the prevailing wage rate determined by the department under sub. (3) or has paid less than 1.5 times the hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor, the department shall order the contractor to pay to any affected employee the amount of his or her unpaid wages or his or her unpaid overtime compensation and an additional amount equal to 100 percent of the amount of those unpaid wages or that unpaid overtime compensation as liquidated damages within a period specified by the department in the order.

AB748-SA2,113,4 3. In addition to or in lieu of recovering the liability specified in subd. 1. as provided in subd. 2., any employee for and in behalf of that employee and other employees similarly situated may commence an action to recover that liability in any court of competent jurisdiction. If the court finds that a contractor, subcontractor, or contractor's or subcontractor's agent has failed to pay the prevailing wage rate determined by the department under sub. (3) or has paid less than 1.5 times the hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor, the court shall order the contractor, subcontractor, or agent to pay to any affected employee the amount of his or her unpaid wages or his or her unpaid overtime compensation and an additional amount equal to 100 percent of the amount of those unpaid wages or that unpaid overtime compensation as liquidated damages.

AB748-SA2,113,9 5. No employee may be a party plaintiff to an action under subd. 3. unless the employee consents in writing to become a party and the consent is filed in the court in which the action is brought. Notwithstanding s. 814.04 (1), the court shall, in addition to any judgment awarded to the plaintiff, allow reasonable attorney fees and costs to be paid by the defendant.

AB748-SA2,113,13 (am) Except as provided in pars. (b), (d), and (f), any contractor, subcontractor, or contractor's or subcontractor's agent who violates this section may be fined not more than $200 or imprisoned for not more than 6 months or both. Each day that a violation continues is a separate offense.

AB748-SA2,113,21 (b) Whoever induces any person who seeks to be or is employed on any project of public works that is subject to this section to give up, waive, or return any part of the wages to which the person is entitled under the contract governing the project, or who reduces the hourly basic rate of pay normally paid to a person for work on a project that is not subject to this section during a week in which the person works both on a project of public works that is subject to this section and on a project that is not subject to this section, by threat not to employ, by threat of dismissal from employment, or by any other means is guilty of an offense under s. 946.15 (1).

AB748-SA2,114,6 (c) Any person employed on a project of public works that is subject to this section who knowingly permits a contractor, subcontractor, or contractor's or subcontractor's agent to pay him or her less than the prevailing wage rate set forth in the contract governing the project, who gives up, waives, or returns any part of the compensation to which he or she is entitled under the contract, or who gives up, waives, or returns any part of the compensation to which he or she is normally entitled for work on a project that is not subject to this section during a week in which the person works both on a project of public works that is subject to this section and on a project that is not subject to this section, is guilty of an offense under s. 946.15 (2).

AB748-SA2,114,12 (d) Whoever induces any person who seeks to be or is employed on any project of public works that is subject to this section to permit any part of the wages to which the person is entitled under the contract governing the project to be deducted from the person's pay is guilty of an offense under s. 946.15 (3), unless the deduction would be permitted under 29 CFR 3.5 or 3.6 from a person who is working on a project that is subject to 40 USC 3142.

AB748-SA2,114,18 (e) Any person employed on a project of public works that is subject to this section who knowingly permits any part of the wages to which he or she is entitled under the contract governing the project to be deducted from his or her pay is guilty of an offense under s. 946.15 (4), unless the deduction would be permitted under 29 CFR 3.5 or 3.6 from a person who is working on a project that is subject to 40 USC 3142.

AB748-SA2,114,21 (f) Paragraph (am) does not apply to any person who fails to provide any information to the department to assist the department in determining prevailing wage rates under sub. (3) (a) or (am).

AB748-SA2,115,8 (7) Debarment. (a) Except as provided under pars. (b) and (c), the department shall distribute to all state agencies a list of all persons whom the department has found to have failed to pay the prevailing wage rate determined under sub. (3) or has found to have paid less than 1.5 times the hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor at any time in the preceding 3 years. The department shall include with any name the address of the person and shall specify when the person failed to pay the prevailing wage rate and when the person paid less than 1.5 times the hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor. A state agency may not award any contract to the person unless otherwise recommended by the department or unless 3 years have elapsed from the date the department issued its findings or date of final determination by a court of competent jurisdiction, whichever is later.

AB748-SA2,115,13 (b) The department may not include in a notification under par. (a) the name of any person on the basis of having let work to a person whom the department has found to have failed to pay the prevailing wage rate determined under sub. (3) or has found to have paid less than 1.5 times the hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor.

AB748-SA2,115,17 (c) This subsection does not apply to any contractor, subcontractor, or agent who in good faith commits a minor violation of this section, as determined on a case-by-case basis through administrative hearings with all rights to due process afforded to all parties or who has not exhausted or waived all appeals.

AB748-SA2,116,2 (d) Any person submitting a bid on a project of public works that is subject to this section shall, on the date the person submits the bid, identify any construction business in which the person, or a shareholder, officer, or partner of the person if the person is a business, owns or has owned at least a 25 percent interest on the date the person submits the bid or at any other time within 3 years preceding the date the person submits the bid, if the business has been found to have failed to pay the prevailing wage rate determined under sub. (3) or to have paid less than 1.5 times the hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor.

AB748-SA2,116,3 (e) The department shall promulgate rules to administer this subsection.

AB748-SA2,117 Section 117. 103.50 of the statutes is created to read:

AB748-SA2,116,5 103.50 Highway contracts. (1) Definitions. In this section:

AB748-SA2,116,12 (a) “Area" means the county in which a proposed project that is subject to this section is located or, if the department determines that there is insufficient wage data in that county, “area" means those counties that are contiguous to that county or, if the department determines that there is insufficient wage data in those counties, “area" means those counties that are contiguous to those counties or, if the department determines that there is insufficient wage data in those counties, “area" means the entire state.

AB748-SA2,116,13 (b) “Hourly basic rate of pay" has the meaning given in s. 103.49 (1) (b).

AB748-SA2,116,14 (bg) “Insufficient wage data" has the meaning given in s. 103.49 (1) (bg).

AB748-SA2,116,15 (c) “Prevailing hours of labor" has the meaning given in s. 103.49 (1) (c).

AB748-SA2,116,20 (d) 1. Except as provided in subd. 2., “prevailing wage rate" for any trade or occupation in any area means the hourly basic rate of pay, plus the hourly contribution for health insurance benefits, vacation benefits, pension benefits, and any other bona fide economic benefit, paid directly or indirectly, for a majority of the hours worked in the trade or occupation in the area.

AB748-SA2,117,2 2. If there is no rate at which a majority of the hours worked in the trade or occupation in the area is paid, “prevailing wage rate" means the average hourly basic rate of pay, weighted by the number of hours worked, plus the average hourly contribution, weighted by the number of hours worked, for health insurance benefits, vacation benefits, pension benefits, and any other bona fide economic benefit, paid directly or indirectly for all hours worked at the hourly basic rate of pay of the highest-paid 51 percent of hours worked in that trade or occupation in that area.

AB748-SA2,117,3 (e) “Truck driver" has the meaning given in s. 103.49 (1) (g).

AB748-SA2,117,14 (2) Prevailing wage rates and hours of labor. No person performing the work described in sub. (2m) in the employ of a contractor, subcontractor, agent, or other person performing any work on a project under a contract based on bids as provided in s. 84.06 (2) to which the state is a party for the construction or improvement of any highway may be permitted to work a greater number of hours per day or per week than the prevailing hours of labor; nor may he or she be paid a lesser rate of wages than the prevailing wage rate in the area in which the work is to be done determined under sub. (3); except that any such person may be permitted or required to work more than such prevailing hours of labor per day and per week if he or she is paid for all hours worked in excess of the prevailing hours of labor at a rate of at least 1.5 times his or her hourly basic rate of pay.

AB748-SA2,117,19 (2g) Nonapplicability. This section does not apply to a single-trade project of public works, as defined in s. 103.49 (1) (em), for which the estimated project cost of completion is less than $48,000 or a multiple-trade project of public works, as defined in s. 103.49 (1) (br), for which the estimated project cost of completion is less than $100,000.

AB748-SA2,117,24 (2m) Covered employees. (a) Subject to par. (b), all of the following employees shall be paid the prevailing wage rate determined under sub. (3) and may not be permitted to work a greater number of hours per day or per week than the prevailing hours of labor, unless they are paid for all hours worked in excess of the prevailing hours of labor at a rate of at least 1.5 times their hourly basic rate of pay:

AB748-SA2,118,2 1. All laborers, workers, mechanics, and truck drivers employed on the site of a project that is subject to this section.

AB748-SA2,118,7 2. All laborers, workers, mechanics, and truck drivers employed in the manufacturing or furnishing of materials, articles, supplies, or equipment on the site of a project that is subject to this section or from a facility dedicated exclusively, or nearly so, to a project that is subject to this section by a contractor, subcontractor, agent, or other person performing any work on the site of the project.

AB748-SA2,118,15 (b) A laborer, worker, mechanic, or truck driver who is employed to process, manufacture, pick up, or deliver materials or products from a commercial establishment that has a fixed place of business from which the establishment supplies processed or manufactured materials or products or from a facility that is not dedicated exclusively, or nearly so, to a project that is subject to this section is not entitled to receive the prevailing wage rate determined under sub. (3) or to receive at least 1.5 times his or her hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor unless any of the following applies:

AB748-SA2,118,20 1. The laborer, worker, mechanic, or truck driver is employed to go to the source of mineral aggregate such as sand, gravel, or stone and deliver that mineral aggregate to the site of a project that is subject to this section by depositing the material directly in final place, from the transporting vehicle or through spreaders from the transporting vehicle.

AB748-SA2,118,24 2. The laborer, worker, mechanic, or truck driver is employed to go to the site of a project that is subject to this section, pick up excavated material or spoil from the site of the project, and transport that excavated material or spoil away from the site of the project and return to the site of the project.

AB748-SA2,119,2 (c) A truck driver who is an owner-operator of a truck shall be paid separately for his or her work and for the use of his or her truck.

AB748-SA2,119,8 (3) Investigations; determinations. The department shall conduct investigations and hold public hearings necessary to define the trades or occupations that are commonly employed in the highway construction industry and to inform itself as to the prevailing wage rates in all areas of the state for those trades or occupations, in order to ascertain and determine the prevailing wage rates accordingly.

AB748-SA2,119,20 (4) Certification of prevailing wage rates. The department of workforce development shall, by May 1 of each year, certify to the department of transportation the prevailing wage rates in each area for all trades or occupations commonly employed in the highway construction industry. The certification shall, in addition to the current prevailing wage rates, include future prevailing wage rates when such prevailing wage rates can be determined for any such trade or occupation in any area and shall specify the effective date of those future prevailing wage rates. The certification shall also include wage rates for work performed on Sundays or the holidays specified in s. 103.49 (1) (c) and shift differentials based on the time of day or night when work is performed. If a construction project extends into more than one area, there shall be but one standard of prevailing wage rates for the entire project.

AB748-SA2,120,2 (4m) Wage rate data. In determining prevailing wage rates for projects that are subject to this section, the department shall use data from projects that are subject to this section, s. 66.0903 or 103.49, or 40 USC 3142. In determining prevailing wage rates for those projects, the department may not use data from any construction work that is performed by a state agency or a local governmental unit, as defined in s. 66.0903 (1) (d).

AB748-SA2,120,6 (5) Appeals to governor. If the department of transportation considers any determination of the department of workforce development as to the prevailing wage rates in an area to have been incorrect, it may appeal to the governor, whose determination shall be final.

AB748-SA2,120,22 (6) Contents of contracts. A reference to the prevailing wage rates determined under sub. (3) and the prevailing hours of labor shall be published in the notice issued for the purpose of securing bids for a project. If any contract or subcontract for a project that is subject to this section is entered into, the prevailing wage rates determined under sub. (3) and the prevailing hours of labor shall be physically incorporated into and made a part of the contract or subcontract, except that for a minor subcontract, as determined by the department of workforce development, that department shall prescribe by rule the method of notifying the minor subcontractor of the prevailing wage rates and prevailing hours of labor applicable to the minor subcontract. The prevailing wage rates and prevailing hours of labor applicable to a contract or subcontract may not be changed during the time that the contract or subcontract is in force. For the information of the employees working on the project, the prevailing wage rates determined by the department, the prevailing hours of labor, and the provisions of subs. (2) and (7) shall be kept posted by the department of transportation in at least one conspicuous and easily accessible place on the site of the project.

AB748-SA2,121,2 (7) Penalties. (a) Except as provided in pars. (b), (d), and (f), any contractor, subcontractor, or contractor's or subcontractor's agent who violates this section may be fined not more than $200 or imprisoned for not more than 6 months or both. Each day that a violation continues is a separate offense.

AB748-SA2,121,10 (b) Whoever induces any person who seeks to be or is employed on any project that is subject to this section to give up, waive, or return any part of the wages to which the person is entitled under the contract governing the project, or who reduces the hourly basic rate of pay normally paid to a person for work on a project that is not subject to this section during a week in which the person works both on a project that is subject to this section and on a project that is not subject to this section, by threat not to employ, by threat of dismissal from employment or by any other means is guilty of an offense under s. 946.15 (1).

AB748-SA2,121,19 (c) Any person employed on a project that is subject to this section who knowingly permits a contractor, subcontractor, or contractor's or subcontractor's agent to pay him or her less than the prevailing wage rate set forth in the contract governing the project, who gives up, waives, or returns any part of the compensation to which he or she is entitled under the contract, or who gives up, waives, or returns any part of the compensation to which he or she is normally entitled for work on a project that is not subject to this section during a week in which the person works both on a project that is subject to this section and on a project that is not subject to this section, is guilty of an offense under s. 946.15 (2).

AB748-SA2,121,25 (d) Whoever induces any person who seeks to be or is employed on any project that is subject to this section to permit any part of the wages to which the person is entitled under the contract governing the project to be deducted from the person's pay is guilty of an offense under s. 946.15 (3), unless the deduction would be permitted under 29 CFR 3.5 or 3.6 from a person who is working on a project that is subject to 40 USC 3142.

AB748-SA2,122,5 (e) Any person employed on a project that is subject to this section who knowingly permits any part of the wages to which he or she is entitled under the contract governing the project to be deducted from his or her pay is guilty of an offense under s. 946.15 (4), unless the deduction would be permitted under 29 CFR 3.5 or 3.6 from a person who is working on a project that is subject to 40 USC 3142.

AB748-SA2,122,8 (f) Paragraph (a) does not apply to any person who fails to provide any information to the department to assist the department in determining prevailing wage rates under sub. (3) or (4).

AB748-SA2,122,18 (8) Enforcement and prosecution. The department of transportation shall require adherence to subs. (2), (2m), and (6). The department of transportation may demand and examine, and every contractor, subcontractor, and contractor's or subcontractor's agent shall keep and furnish upon request by the department of transportation, copies of payrolls and other records and information relating to compliance with this section. Upon request of the department of transportation or upon complaint of alleged violation, the district attorney of the county in which the work is located shall investigate as necessary and prosecute violations in a court of competent jurisdiction. Section 111.322 (2m) applies to discharge and other discriminatory acts arising in connection with any proceeding under this section.

AB748-SA2,118 Section 118. 103.503 (1) (a) of the statutes, as affected by 2017 Wisconsin Act 59, is amended to read:

AB748-SA2,123,2 103.503 (1) (a) “Accident" means an incident caused, contributed to, or otherwise involving an employee that resulted or could have resulted in death, personal injury, or property damage and that occurred while the employee was performing the work described in s. 66.0903 (4), 2013 stats., or s. 16.856 103.49 (2m), 2015 stats., on a project of public works or while the employee was performing work on a public utility project.

AB748-SA2,119 Section 119. 103.503 (1) (e) of the statutes, as affected by 2017 Wisconsin Act 59, is amended to read:

AB748-SA2,123,7 103.503 (1) (e) “Employee" means a laborer, worker, mechanic, or truck driver who performs the work described in s. 66.0903 (4), 2013 stats., or s. 16.856 103.49 (2m), 2015 stats., on a project of public works or on a public utility project.

AB748-SA2,120 Section 120. 103.503 (1) (g) of the statutes, as affected by 2017 Wisconsin Act 59, is repealed and recreated to read:

AB748-SA2,123,11 103.503 (1) (g) “Project of public works" means a project of public works that is subject to s. 66.0903 or 103.49.

AB748-SA2,121 Section 121. 103.503 (2) of the statutes, as affected by 2017 Wisconsin Act 59, is amended to read:

AB748-SA2,123,21 103.503 (2) Substance abuse prohibited. No employee may use, possess, attempt to possess, distribute, deliver, or be under the influence of a drug, or use or be under the influence of alcohol, while performing the work described in s. 66.0903 (4), 2013 stats., or s. 16.856 103.49 (2m), 2015 stats., on a project of public works or while performing work on a public utility project. An employee is considered to be under the influence of alcohol for purposes of this subsection if he or she has an alcohol concentration that is equal to or greater than the amount specified in s. 885.235 (1g) (d).

AB748-SA2,122 Section 122. 103.503 (3) (a) 2. of the statutes, as affected by 2017 Wisconsin Act 59, is amended to read:

AB748-SA2,124,6 103.503 (3) (a) 2. A requirement that employees performing the work described in s. 66.0903 (4), 2013 stats., or s. 16.856 103.49 (2m), 2015 stats., on a project of public works or performing work on a public utility project submit to random, reasonable suspicion, and post-accident drug and alcohol testing and to drug and alcohol testing before commencing work on the project, except that testing of an employee before commencing work on a project is not required if the employee has been participating in a random testing program during the 90 days preceding the date on which the employee commenced work on the project.

AB748-SA2,123 Section 123. 104.001 (4) of the statutes is created to read:

AB748-SA2,124,11 104.001 (4) This section does not affect the requirement that employees employed on a public works project contracted for by a city, village, town, or county be paid at the prevailing wage rate, as defined in s. 66.0903 (1) (g), as required under s. 66.0903.

AB748-SA2,124 Section 124. 106.04 of the statutes is created to read:

AB748-SA2,124,16 106.04 Employment of apprentices on state public works projects. (1) Definition. In this section, “project" means a project of public works that is subject to s. 103.49 or 103.50 in which work is performed by employees employed in trades that are apprenticeable under this subchapter.

AB748-SA2,124,21 (2) Waiver. If the department grants an exception or modification to any requirement in any contract for the performance of work on a project relating to the employment and training of apprentices, the department shall post that information on its Internet site, together with a detailed explanation of why the exception or modification was granted.

AB748-SA2,125 Section 125. 109.09 (1) of the statutes, as affected by 2017 Wisconsin Act 59, is amended to read:

AB748-SA2,125,20 109.09 (1) The department shall investigate and attempt equitably to adjust controversies between employers and employees as to alleged wage claims. The department may receive and investigate any wage claim that is filed with the department, or received by the department under s. 109.10 (4), no later than 2 years after the date the wages are due. The department may, after receiving a wage claim, investigate any wages due from the employer against whom the claim is filed to any employee during the period commencing 2 years before the date the claim is filed. The department shall enforce this chapter and s. ss. 66.0903, 2013 stats., s. 103.49, 2013 stats., s. 229.8275, 2013 stats., and s. 16.856, 2015 stats., and ss. 103.02, 103.49, 103.82, and 104.12, and 229.8275. In pursuance of this duty, the department may sue the employer on behalf of the employee to collect any wage claim or wage deficiency and ss. 109.03 (6) and 109.11 (2) and (3) shall apply to such actions. Except for actions under s. 109.10, the department may refer such an action to the district attorney of the county in which the violation occurs for prosecution and collection and the district attorney shall commence an action in the circuit court having appropriate jurisdiction. Any number of wage claims or wage deficiencies against the same employer may be joined in a single proceeding, but the court may order separate trials or hearings. In actions that are referred to a district attorney under this subsection, any taxable costs recovered by the district attorney shall be paid into the general fund of the county in which the violation occurs and used by that county to meet its financial responsibility under s. 978.13 (2) (b) for the operation of the office of the district attorney who prosecuted the action.

AB748-SA2,126 Section 126. 111.322 (2m) (a) of the statutes is amended to read:

AB748-SA2,125,25 111.322 (2m) (a) The individual files a complaint or attempts to enforce any right under s. 103.02, 103.10, 103.11, 103.13, 103.28, 103.32, 103.34, 103.455, 103.50, 104.12, 109.03, 109.07, 109.075, 146.997, or 995.55, or ss. 101.58 to 101.599 or 103.64 to 103.82.

AB748-SA2,127 Section 127. 111.322 (2m) (b) of the statutes is amended to read:

AB748-SA2,126,5 111.322 (2m) (b) The individual testifies or assists in any action or proceeding held under or to enforce any right under s. 103.02, 103.10, 103.11, 103.13, 103.28, 103.32, 103.34, 103.50, 103.455, 104.12, 109.03, 109.07, 109.075, 146.997, or 995.55, or ss. 101.58 to 101.599 or 103.64 to 103.82.

AB748-SA2,128 Section 128. 111.322 (2m) (c) of the statutes is created to read:

AB748-SA2,126,9 111.322 (2m) (c) The individual files a complaint or attempts to enforce a right under s. 66.0903, 103.49, or 229.8275 or testifies or assists in any action or proceeding under s. 66.0903, 103.49, or 229.8275.

AB748-SA2,129 Section 129. 227.01 (13) (t) of the statutes is created to read:

AB748-SA2,126,14 227.01 (13) (t) Ascertains and determines prevailing wage rates under ss. 66.0903, 103.49, 103.50, and 229.8275, except that any action or inaction which ascertains and determines prevailing wage rates under ss. 66.0903, 103.49, 103.50, and 229.8275 is subject to judicial review under s. 227.40.

AB748-SA2,130 Section 130. 229.682 (2) of the statutes is created to read:

AB748-SA2,126,17 229.682 (2) Prevailing wage. The construction of a baseball park facility that is financed in whole or in part by a district is subject to s. 66.0903.

AB748-SA2,131 Section 131. 229.8275 of the statutes is created to read: