16.848(11)(h)
(h) Cogeneration systems that produce steam or forms of energy such as heat, as well as electricity, for use primarily within a building or complex of buildings.
16.848(11)(j)
(j) Any other facility improvement measure that is designed to provide long-term energy or operating cost reductions or compliance with state or local building codes.
16.848 History
History: 1995 a. 27.
ENGINEERING
16.85
16.85
Department of administration; powers, duties. The department of administration shall exercise the powers and duties prescribed by
ss. 16.85 to
16.91:
16.85(1)
(1) To take charge of and supervise all engineering or architectural services or construction work as defined in
s. 16.87 performed by, or for, the state, or any department, board, institution, commission or officer thereof, including nonprofit-sharing corporations organized for the purpose of assisting the state in the construction and acquisition of new buildings or improvements and additions to existing buildings as contemplated under
ss. 13.488,
36.09 and
36.11, except the engineering, architectural and construction work of the department of transportation, the engineering service performed by the department of commerce, department of revenue, public service commission, department of health and family services and other departments, boards and commissions when the service is not related to the maintenance, construction and planning of the physical properties of the state, and energy efficiency projects of the energy efficiency program under
s. 16.847. The department shall not authorize construction work for any state office facility in the city of Madison after May 11, 1990, unless the department first provides suitable space for a day care center primarily for use by children of state employes.
16.85(2)
(2) To furnish engineering, architectural, project management and other building construction services whenever requisitions therefor are presented to the department by any agency. The department may deposit moneys received from the provision of these services in the account under
s. 20.505 (1) (kc) or in the general fund as general purpose revenue — earned. In this subsection, "agency" means an office, department, independent agency, institution of higher education, association, society or other body in state government created or authorized to be created by the constitution or any law, which is entitled to expend moneys appropriated by law, including the legislature and the courts, but not including an authority created in
ch. 231,
233 or
234.
16.85(3)
(3) To act and assist any department, board, commission or officer requesting such cooperation and assistance, in letting contracts for engineering or architectural work authorized by law and in supervising the work done thereunder;
16.85(4)
(4) To approve the appointment of a chief operating engineer for each state-owned or operated heating, cooling or power plant and pumping station, to provide for the methods of operating the plants and stations and to design records and forms for reporting accurately the cost per unit of product or service. The superintendent or other person having charge of each plant or station shall not only report to the agency which operates the plant or station but to the secretary in the manner and at such times as the secretary determines. In this subsection, "agency" has the meaning given under
sub. (2).
16.85(5)
(5) To promote the use of energy conservation methods in state-owned facilities, to implement and refine a statewide energy monitoring system and to develop and implement initiatives of replacing fossil fuels with renewable energy fuels.
16.85(6)
(6) To approve the appointment of a principal engineer or architect for departments, boards and commissions and when such continuous service is needed. No such engineer or architect shall be employed without the written approval of the secretary.
16.85(7)
(7) To rebuild and repair discarded machinery of the several state institutions when found feasible, and put the same back into service in the same department or in any other state department, and upon requisition to furnish services and material and loan equipment at fair rentals based on the cost thereof, in connection with the construction, operation and maintenance of heating and power plants, utilities and equipment.
16.85(8)
(8) The secretary or the secretary's designated assistants shall make a biennial inspection of each building of each institution of the state. The secretary may delegate this responsibility to the board, commission or officer in charge of such institution.
16.85(10)
(10) To prepare in cooperation with the state agencies concerned, plans for the future growth and development of various state institutions and to serve as technical adviser to the building commission in connection with the development of the state long-range building program provided in
ss. 13.48 and
13.482.
16.85(11)
(11) The secretary may delegate any of the work under this subchapter to the various state agencies when the secretary determines that the best interests of the state will be served. All such delegation will be in writing and accompanied by the proper rules and guidelines the agencies must follow to ensure performance to the satisfaction of the secretary.
16.85(12)
(12) To review and approve plans and specifications for any building or structure that is constructed for the benefit of the university of Wisconsin system or any institution thereof, and to periodically review the progress of any such building or structure during construction to assure compliance with the approved plans and specifications.
16.85(14)
(14) To review and approve the design and specifications of any construction or improvement project of the University of Wisconsin Hospitals and Clinics Authority on state-owned land, to approve the decision to construct any such construction or improvement project and to periodically review the progress of the project during construction to assure compliance with the approved design and specifications. This subsection does not apply to any construction or improvement project of the authority that costs less than the amount that is required to be specified in the lease agreement between the authority and the board of regents of the University of Wisconsin System under
s. 233.04 (7) (d).
16.851
16.851
Plans for state buildings, structures or facilities. Except as the department otherwise provides by rule, records of the department containing plans or specifications for any state-owned or state-leased building, structure or facility, or any proposed state-owned or state-leased building, structure or facility, are not subject to the right of public inspection or copying under
s. 19.35 (1). If the department transfers any records containing any such plans or specifications to any other authority as defined in
s. 19.32 (1), the department shall require the authority to agree in writing not to make the record available for public inspection or copying except as the department otherwise permits by rule.
16.851 History
History: 1995 a. 27.
16.854
16.854
Services provided to professional baseball park districts. 16.854(1)(c)
(c) "Women's business" means a sole proprietorship, partnership, joint venture or corporation that is at least 51% owned, controlled and actively managed by women.
16.854(2)
(2) Subject to the requirements of
s. 16.82 (7), the department may, upon request of any local professional baseball park district, if the district has entered into a lease agreement with the department under
s. 16.82 (7), take charge of and supervise engineering or architectural services or construction work, as defined in
s. 16.87, performed by, or for, the district for compensation to be agreed upon between the department and the district. In connection with such services or work, the department may furnish engineering, architectural, project management and other building construction services whenever requisitions therefor are presented to the department by the district. If the district has entered into a lease agreement with the department under
s. 16.82 (7), the department may also assist the district, upon request of the district, in letting contracts for engineering, architectural or construction work authorized by law and in supervising the work done thereunder. The department may award any such contract for any combination or division of work it designates and may consider any factors in awarding a contract including price, time for completion of work and the qualifications and past performance of a contractor. In awarding contracts under this section for the construction of baseball park facilities, as defined in
s. 229.65 (1), the department shall ensure that any person who is awarded a contract agrees, as a condition to receiving the contract, that his or her goal shall be to ensure that at least 25% of the employes hired because of the contract will be minority group members and at least 5% of the employes hired because of the contract will be women. It shall also be a goal of the department to ensure that at least 25% of the aggregate dollar value of contracts awarded for the construction of such facilities in the following areas are awarded to minority businesses and at least 5% of the aggregate dollar value of contracts awarded for the construction of such facilities in the following areas are awarded to women's businesses:
16.854(2)(a)
(a) Contracts for the construction of baseball park facilities.
16.854(2)(b)
(b) Contracts for professional services related to the construction of baseball park facilities.
16.854(2)(c)
(c) Contracts for the development of baseball park facilities.
16.854(3)
(3) It shall be a goal of the department, with regard to each of the contracts described under
sub. (2) (a),
(b) and
(c), to award at least 25% of the dollar value of such contracts to minority businesses and at least 5% of the dollar value of such contracts to women's businesses.
Sections 16.85,
16.855 and
16.87 do not apply to services provided or contracted by the department under this section.
16.854 History
History: 1995 a. 56.
16.855
16.855
Construction project contracts. 16.855(1)
(1) The department shall let by contract to the lowest qualified responsible bidder all construction work when the estimated construction cost of the project exceeds $30,000, except as provided in
sub. (10m) or
s. 13.48 (19). If a bidder is not a Wisconsin firm and the department determines that the state, foreign nation or subdivision thereof in which the bidder is domiciled grants a preference to bidders domiciled in that state, nation or subdivision in making governmental purchases, the department shall give a preference over that bidder to Wisconsin firms, if any, when awarding the contract, in the absence of compelling reasons to the contrary. The department may enter into agreements with states, foreign nations and subdivisions thereof for the purpose of implementing this subsection.
16.855(2)
(2) Whenever the estimated construction cost of a project exceeds $30,000, or if less and in the best interest of the state, the department shall:
16.855(2)(a)
(a) Advertise for proposals by publication of a class 1 notice, under
ch. 985, in the official state newspaper. Similar notices may be placed in publications likely to inform potential bidders of the project. The department may solicit bids from qualified contractors to insure adequate competition. All advertisements shall contain the following information:
16.855(2)(b)1.1. Require that a guarantee of not less than 10% of the amount of the bid shall be included with each bid submitted guaranteeing the execution of the contract within 10 days of offering, if offered within 30 days after the date set for the opening thereof. The parties may agree to extend the time for offering of the contract beyond 30 days after the opening of bids.
16.855(2)(b)2.
2. If the federal government participates in a state project, the bid guarantee required in this paragraph controls, unless the federal government makes a specific provision for a different bid guarantee.
16.855(2)(c)
(c) Publicly open and read aloud, at the time and place specified in the notice, all bids. Within a reasonable time after opening, tabulations of all bids received shall be available for public inspection.
16.855(2)(d)
(d) Not allow or make any correction or alteration of a bid, except as provided in
sub. (6).
16.855(3)
(3) At any time prior to the published time of opening, a bid may be withdrawn on written request submitted to the department by the bidder or the bidder's agent, without prejudice to the right of the bidder to file a new bid.
16.855(4)
(4) If a bid contains an error, omission or mistake, the bidder may limit liability to the amount of the bidder's bid guarantee by giving written notice of intent not to execute the contract to the department within 72 hours of the bid opening. The department of administration, with the approval of the attorney general, may settle and dispose of cases and issues arising under this subsection. However, if no such settlement is obtained, the bidder is not entitled to recover the bid guarantee unless the bidder proves in the circuit court for Dane county that in making the mistake, error or omission the bidder was free from negligence.
16.855(5)
(5) Any or all bids may be rejected if, in the opinion of the department, it is in the best interest of the state. The reasons for rejection shall be given to the bidder or bidders in writing.
16.855(6)
(6) Nothing contained in this section shall prevent the department from negotiating deductive changes in the lowest qualified bid.
16.855(7)
(7) The department may issue contract change orders, if they are deemed to be in the best interests of the state.
16.855(9)
(9) The department may require bidders to submit sworn statements as to financial ability, equipment and experience in construction and require such other information as may be necessary to determine their competency.
16.855(10)
(10) When the department believes that it is in the best interests of the state to contract for certain articles or materials available from only one source, it may contract for said articles or materials without the usual statutory procedure, after a publication of a class 1 notice, under
ch. 985, in the official state newspaper.
16.855(10m)(a)(a) In awarding construction contracts the department shall attempt to ensure that 5% of the total amount expended in each fiscal year is awarded to contractors and subcontractors which are minority businesses, as defined under
s. 16.75 (3m) (a). The department may award any contract to a minority business that submits a qualified responsible bid that is no more than 5% higher than the apparent low bid.
16.855(10m)(b)
(b) Upon completion of any contract, the contractor shall report to the department any amount of the contract that was subcontracted to minority businesses.
16.855(10m)(c)
(c) The department shall maintain and annually publish data on contracts awarded to minority businesses under this subsection and
ss. 16.87 and
84.075.
16.855(10p)
(10p) For each proposed construction project, the department shall ensure that the specifications require the use of recovered materials and recycled materials, as defined under
s. 16.70 (11) and
(12), to the extent that such use is technically and economically feasible.
16.855(11)
(11) A contractor shall be liable for any damages to another contractor working on the same project caused by reason of the former's default, act or nonperformance.
16.855(12)
(12) Nothing contained in this section shall be construed so as to make contracts let under this section subject to
s. 66.29.
16.855(13)(a)(a) A list of subcontractors shall not be required to be submitted with the bid. The department may require the successful bidder to submit in writing the names of prospective subcontractors for the department's approval before the award of a contract to the prime contractor.
16.855(13)(b)
(b) All subcontractors must be approved in writing by the department prior to their employment. Requests for approval of prospective subcontractors shall be in writing.
16.855(13)(c)
(c) Changes may be made in the list of subcontractors, with the agreement of the department and the prime contractor, when in the opinion of the department it is in the best interests of the state to require the change.
16.855(14)(a)(a) If the estimated construction cost of a project exceeds $100,000, the department shall take both single bids and separate bids on any division of the work that it designates. If the estimated construction cost of a project does not exceed $100,000 and bids are required to be solicited under
sub. (2), the department may take single bids or separate bids on any division of the work that it designates. If the department awards contracts by the division of work, the department shall award the contracts according to the division of work selected for bidding. Except as provided in
sub. (10m) (a), the department shall award all contracts to the lowest qualified responsible bidder or bidders that result in the lowest total construction cost for the project.
16.855(14)(b)
(b) The state is not liable to a prime contractor for damage from delay caused by another prime contractor if the department takes reasonable action to require the delaying prime contractor to comply with its contract. If the state is not liable under this paragraph, the delayed prime contractor may bring an action for damages against the delaying prime contractor.
16.855(15)
(15) The department shall promulgate rules to implement the advertising and award of contracts.
16.855(16)(a)(a) This section does not apply to contracts between the state and federal government or any agency thereof, or with any political subdivision of the state. Subject to the approval of the governor, the requirements of this section may be waived in emergency situations involving the public health, welfare or safety or with respect to contracting with public utilities, but only when any such waiver is deemed by the governor to be in the best interests of the state.
16.855(16)(b)2.
2. In emergency situations, the governor may approve repairs and construction in lieu of building commission approval under
s. 13.48 (10), and for such purposes, may authorize the expenditure of up to $250,000 from the state building trust fund or from other available moneys appropriated to an agency derived from any revenue source. The governor shall report any such authorization to the building commission at its next regular meeting following the authorization.
16.855(17)
(17) This section does not apply to any project on which the work is to be performed by inmates or patients in institutions under the jurisdiction of the department of corrections or the department of health and family services working under the supervision or with the assistance of state employes.
16.855(18)
(18) This section shall not apply to restoration or reconstruction of the state capitol building, historic structures at the old world Wisconsin site and at Heritage Hill state park when the department determines that a waiver of this section would serve the best interests of this state.
16.855(19)
(19) As the work progresses under any contract for construction the department, from time to time, shall grant to the contractor an estimate of the amount and proportionate value of the work done, which shall entitle the contractor to receive the amount thereof, less the retainage, from the proper fund. On all construction projects, the retainage shall be an amount equal to 10% of said estimate until 50% of the work has been completed. At 50% completion, no additional amounts shall be retained, and partial payments shall be made in full to the contractor unless the architect or engineer certifies that the job is not proceeding satisfactorily. At 50% completion or any time thereafter when the progress of the work is not satisfactory, additional amounts may be retained but in no event shall the total retainage be more than 10% of the value of the work completed. Upon substantial completion of the work, an amount retained may be paid to the contractor. For the purposes of this section, estimates may include any fabricated or manufactured materials and components specified, previously paid for by contractor and delivered to the work or properly stored and suitable for incorporation in the work embraced in the contract.
16.855(20)
(20) This section does not apply to construction work performed by university of Wisconsin system students when the construction work performed is a part of a curriculum and where the work is course-related for the student involved. Prior approval of the building commission must be obtained for all construction projects to be performed by university of Wisconsin system students.
16.855(21)
(21) This section does not apply to contracts by the department of natural resources for construction work related to hazardous substance spill response under
s. 292.11 or environmental repair under
s. 292.31.
16.855 Annotation
Construing (2) (a) 2. and (14), it is held that the department has authority to create a division of work not limited to traditional trade practices, which may include work divisions other than the four enumerated in the statute if the new division involves a specialized area of construction, e.g., elevator work which is commonly designated a division although it involves the electrical trade. Breiby v. Dept. of Administration, 55 W (2d) 16, 197 NW (2d) 737.
16.855 Annotation
A bid proposal asking for the name of a subcontractor is contrary to (13) (a), and the request is invalid. 61 Atty. Gen. 224.
16.865
16.865
Department of administration; statewide risk management coordination. The department shall:
16.865(1)
(1) Be responsible for statewide risk management coordination in order to:
16.865(1)(a)
(a) Protect the state from losses which are catastrophic in nature and minimize total cost to the state of all activities related to the control of accidental loss.
16.865(1)(b)
(b) Place emphasis on the reduction of loss through professional attention to scientific loss control techniques and by motivational incentives, prompt claims payments and other loss prevention measures.
16.865(2)
(2) Identify and evaluate exposure to loss to the state, its employes or injury to the public by reason of fire or other accidents and fortuitous events at state-owned properties or facilities.
