AB770: Bill Text

Under this bill, no new and additional storm and surface water sewerage system service charge may be made for a property that retains at least 90 percent of storm water falling on the subject property.

Weekend work

Under this bill, a political subdivision may not prohibit a private person from working on a private construction project on a weekend, or impose conditions on the person that are inapplicable to, or more restrictive than conditions that apply to, such a person who works on a construction project during weekdays. If the political subdivision has in effect an ordinance or resolution that is inconsistent with this provision, that ordinance or resolution does not apply and may not be enforced after the bill takes effect.

Uniform dwelling code

This bill prohibits a political subdivision from making or enforcing an ordinance that does not conform to the one-family and two-family dwelling code (commonly called the uniform dwelling code). The bill also provides that, if a contract between a political subdivision and the owner of a dwelling requires the owner to comply with such an ordinance, the owner may waive the provision, and the provision, if waived, is void and unenforceable.

Tax incremental financing, impact fees

This bill authorizes the creation of workforce housing development tax incremental districts and changes the method of imposing certain impact fees.

Under the current tax incremental financing program, a city or village may create a TID in part of its territory to foster development under certain conditions. Currently, towns and counties also have a limited ability to create a TID under certain limited circumstances. Before a city or village may create a TID, several steps and plans are required. These steps and plans include public hearings on the proposed TID within specified time frames, preparation and adoption by the local planning commission of a proposed project plan for the TID, approval of the proposed project plan by the common council or village board, approval of the city's or village's proposed TID by a joint review board (JRB) that consists of members who represent the overlying taxation districts, and adoption of a resolution by the common council or village board that creates the TID as of a date provided in the resolution.

Also under current law, once a TID has been created, the Department of Revenue calculates the “tax incremental base" value of the TID, which is the equalized value of all taxable property within the TID at the time of its creation. If the development in the TID increases the value of the property in the TID above the base value, a “value increment" is created. That portion of taxes collected on the value increment in excess of the base value is called a “tax increment." The tax increment is placed in a special fund that may be used only to pay back the project costs of the TID.

The project costs of a TID, which are initially incurred by the creating city or village, include public works such as sewers, streets, and lighting systems; financing costs; site preparation costs; and professional service costs. DOR authorizes the allocation of the tax increments until the TID terminates or, generally, 20 years, 23 years, or 27 years after the TID is created, depending on the type of TID and the year in which it was created. Also under current law, a city or village may not generally make expenditures for project costs later than five years before the unextended termination date of the TID. Under certain circumstances, the life of the TID, the expenditure period, and the allocation period may be extended. A TID is required to terminate, under current law and with some exceptions, once its project costs are paid back.

Generally under current law, project costs may be expended to benefit residential development but only certain TIDs for which a project plan was approved before September 30, 1995, or for a mix-use development. With regard to a mixed-use development, lands proposed for newly platted residential use may not exceed 35 percent, by area, of real property within the TID.

Under the bill, a workforce housing TID may contain only newly platted residential uses, 100 percent of which must be workforce housing. Before such a TID may be created, the JRB must approve the TID by a unanimous vote. For other TIDs, only a majority vote is required. A workforce housing TID has a maximum life of 15 years, and DOR may allocate tax increments for only 15 years.

Also under the bill, workforce housing is defined to mean housing based on the following two factors, which are subject to the five year average median costs as determined by the U.S. bureau of census:

1. Housing that costs no more than 30 percent of the household's gross monthly income.

2. The construction cost per housing unit, including rental housing, is no more than 80 percent of the median price for new residential construction in the county.

Under current law, a municipality may impose an impact fee on a developer to pay for the capital costs to construct certain public facilities that are necessary to accommodate land development.

Current law requires that impact fees must be used within certain specified periods, depending upon when the ordinance authorizing impact fees was enacted and when the fee was imposed, or be refunded to the current owner of the property for which the impact fees were imposed. Under this bill, impact fees that are not used within eight years after they are collected must be refunded to the current owner of the property.

This bill requires a municipality to prepare an annual report listing the impact fees that have been imposed during the previous year and containing certain additional information related to the municipality's administration of impact fees during the year. The bill also prohibits certain uses of impact fee moneys.

Under current law, if a city, village, or town imposes an impact fee on a developer to pay for certain capital costs that are necessary to accommodate land development, the ordinance may provide for an exemption from, or a reduction in the amount of, impact fees on land development that provides low-cost housing. Under this bill, the impact fee exemption or reduction provisions also apply to workforce housing. Current law prevents the shifting of an exemption from or reduction in impact fees to any other development in the land development in which the low-cost housing is located. The bill applies this provision to workforce housing as well.

Zoning limitations, inspections

The bill provides that if a political subdivision or utility district imposes requirements on a developer related to the installation of a water meter station or a sanitary sewer lift pump station for a development project, the requirements may not require a developer to install more than the minimum level of such a station or its housing that is required to ensure the proper functioning of such a station.

Under the bill, if a political subdivision employs a building inspector to enforce its zoning ordinances or other ordinances related to building, and a developer requests the inspector to perform an inspection, the inspector must complete the inspection not later than 14 business days after receiving the request. If the local inspector does not complete the inspection within this time frame, the bill allows a developer to request that a qualified state inspector perform the required inspection. The political subdivision must accept a certificate of inspection provided by the state building inspector as if it were provided by the local building inspector if the inspection meets the requirements for an inspection that was supposed to have been provided by the local building inspector.

Inclusionary zoning prohibitions

The bill also prohibits a political subdivision from enacting or enforcing an inclusionary zoning ordinance. The bill defines this type of ordinance as one which prescribes that a certain number or percentage of new or existing residential dwelling units in a land development be made available for rent or sale to an individual or family with a family income at or below a certain percentage of the median income.

Plat approval process; public improvements

This bill makes various changes related to security required by a city, village, town, or county (approving authority) as part of the plat approval process. Under current law, as a condition of approving a plat, an approving authority may require a subdivider to execute a surety bond or provide other security to ensure that certain public improvements are made in connection with a project. This bill reduces the maximum amount of security that an approving authority may require from 120 percent of the estimated total cost to complete the required public improvements (estimated completion cost) to 110 percent of the estimated completion cost. The bill also creates limitations on how the estimated completion cost is determined and provides that the total cost of the public improvements includes the cost to make and install storm water facilities, but does not include any fees charged by the approving authority or certain land disturbing activities. This bill explicitly requires an approving authority to accept a performance bond, a letter of credit, or any combination thereof, at the subdivider's option, to satisfy the security requirement.

Upon substantial completion of required public improvements, current law limits both the amount of security that may be required from a subdivider and the length of time during which the security may be required. Under the bill, if the public improvements include roads to be dedicated, substantial completion occurs upon the installation of the asphalt or concrete binder course on the roads to be dedicated. Additionally, under the bill, upon substantial completion, any outstanding local building permits that are related to and dependent upon substantial completion of the required public improvements must be released. Before substantial completion, the bill requires an approving authority to, upon request, issue a permit to commence construction of a foundation or any other noncombustible construction. Finally, the bill prohibits an approving authority from enacting an ordinance related to substantial completion of public improvements that is inconsistent with state law.

Subdivision approval conditions

Under current law, a political subdivision may, as a condition of approval of a subdivision or other division of land (subdivision), require land dedication, easement, or other public improvement by a subdivider. However, a political subdivision is generally prohibited from imposing, as a condition of approval of a subdivision, a fee or other charge to fund the acquisition or improvement of real or personal property, except that a city, village, or town may impose a fee or other charge to fund the acquisition or initial improvement of land for public parks (public park fee). The bill modifies that exception to provide that a city, village, or town may impose a public park fee only if the authorizing ordinance of the city, village, or town is enacted by following the same procedures and requirements that apply to the imposition of impact fees on developers.

The bill also provides that, if a political subdivision's ordinance requires, as a condition of approval of a subdivision, that a subdivider dedicate land for a public park, the political subdivision may offer the subdivider the option of either dedicating the land or paying a fee or other charge in lieu of the dedication. If the subdivider elects to pay the fee or other charge, it is payable by the landowner to the political subdivision upon the issuance of a building permit by the political subdivision.

Construction banners

Except for an ordinance related to health or safety concerns, this bill prohibits a political subdivision from enacting an ordinance or adopting a resolution that limits the owner or other person in control of a construction site from installing a banner over a fence that surrounds the site. Under the bill, such a banner may cover the entire height and length of the fence. If a political subdivision has in effect an ordinance or resolution that is inconsistent with the subject matter of the bill, that ordinance or resolution does not apply and may not be enforced after the bill takes effect.

Storm water management

This bill prohibits a political subdivision from enacting or enforcing an ordinance relating to storm water management unless the ordinance strictly conforms to uniform statewide standards.

Current law allows a political subdivision to enact or enforce provisions that are stricter than uniform statewide standards if necessary to control storm water quantity or control flooding or to comply with federally approved total maximum daily load requirements, or if the provisions regulate storm water management relating to existing development or redevelopment.

Eminent domain

This bill requires that, when determining the fair market value of property that is taken for a public purpose under the eminent domain law, a commission in condemnation or a court consider appraisals of the fair market value based on the sale of comparable properties, based on evidence of the value of future income, and based on evidence of the cost of the market value of the land plus the cost of replacing or reproducing improvements. Under current law, a property owner whose property is taken for a public purpose is entitled to the fair market value of the property taken. The supreme court has held, in Leathem Smith Lodge, Inc. v. State, 94 Wis.2d 406, 288 N.W.2d 808 (1980), that, when determining fair market value, evidence of the income of a business is not admissible if there is evidence of the sale of comparable property.

The bill also makes changes to additional payments required under the eminent domain law to certain persons who are displaced by a condemnation proceeding from a business or farm operation. Under current law, a person who is displaced from the person's business or farm operation as a result of condemnation is entitled to a payment for certain specified costs from the condemnor when that person rents or purchases a comparable replacement business or farm operation. A property owner who is displaced from the owner's business or farm operation and purchases a comparable replacement business or farm operation is entitled to a payment of up to $50,000. A tenant who is displaced from the tenant's business or farm operation and rents or purchases a comparable business or farm operation is entitled to a payment of up to $30,000. This bill makes the following changes:

1. Increases the statutory limitation on additional payments from $50,000 to $100,000 for a property owner who is displaced by a condemnation proceeding from a business or farm operation when the property owner purchases a comparable replacement business or farm operation.

2. Increases the statutory limitation on additional payments from $30,000 to $80,000 for a tenant who is displaced by a condemnation proceeding from a business or farm operation when the tenant leases a comparable replacement business or farm operation.

3. Specifies that a person displaced from the person's business or farm operation is entitled to an amount to pay for costs the person incurs or will incur to make the replacement business or farm operation functionally equivalent to the business or farm operation from which the person was displaced and suitable to remain a going concern. The bill specifies that these costs include cost of capital, financing, professional services, administration, and alterations to or construction of certain infrastructure improvements or public utility infrastructure.

4. Provides that a person displaced by a condemnation proceeding from the person's business or farm operation is entitled to litigation expenses from the condemnor if the person prevails in an action for the determination of the amount of the additional payment.

Local development-related regulation reports

This bill requires municipalities to prepare certain reports related to its regulation of land development. Among the information that must be provided, a municipality must identify certain development-related fees it imposes and the amount of each fee. The municipality must post the reports on the municipality's Internet site. If a fee that is required to be posted is not posted on the municipality's Internet site, the municipality may not charge the fee.

Regulation of rental housing units

This bill prohibits municipalities from regulating the size of a bedroom in a rental unit and from imposing any requirement related to the number of bedrooms in a rental unit.

Zoning amendment protest

Under current law, the common council of a city may adopt amendments to an existing zoning ordinance. Certain affected landowners, however, may protest the amendment. If the amendment is protested, the amendment does not take effect unless three-fourths of the members of the common council approve the amendment. Under current law, a protest may be lodged by 1) owners of property included in the proposed amendment (affected property); 2) owners of property immediately adjacent to, and extending 100 feet from, the affected property; or 3) the owners of property directly opposite the affected property extending 100 feet from the street frontage of the affected property.

This bill provides that a protested amendment takes effect if approved by a majority of the members of the common council. The bill also clarifies that a protesting owner under item 2) or 3) above must be an owner of property located within the city.

For further information see the state and local fiscal estimate, which will be printed as an appendix to this bill.

The people of the state of Wisconsin, represented in senate and assembly, do enact as follows:

AB770,1 Section 1. 32.09 (1m) of the statutes is renumbered 32.09 (1m) (a) and amended to read:

AB770,9,10 32.09 (1m) (a) As a basis for determining value, a commission in condemnation or a court may shall consider the price and other terms and circumstances of any good faith sale or contract to sell and purchase comparable property. A sale or contract is comparable within the meaning of this subsection paragraph if it was made within a reasonable time before or after the date of evaluation and the property is sufficiently similar in the relevant market, with respect to situation, usability, improvements, and other characteristics, to warrant a reasonable belief that it is comparable to the property being valued.

AB770,2 Section 2. 32.09 (1m) (b) of the statutes is created to read:

AB770,9,14 32.09 (1m) (b) As a basis for determining value, a commission in condemnation or a court shall consider an appraisal based on the income approach and an appraisal based on the cost approach.

AB770,3 Section 3. 32.19 (2) (hm) of the statutes is created to read:

AB770,9,18 32.19 (2) (hm) “Reasonable project costs” means the total of all of the following costs that an owner displaced person of an owner-occupied business or farm operation or tenant displaced person of a tenant-occupied business or farm operation must reasonably incur to make a comparable replacement business or farm operation under sub. (4m) functionally equivalent to the business or farm operation from which the owner or tenant is displaced and suitable to remain a going concern:

AB770,10,9 1. Capital costs, including the actual costs of the construction of improvements, new buildings, structures, and fixtures; the demolition, alteration, remodeling, repair or reconstruction of existing buildings, structures, and fixtures; the removal or containment of, or the restoration of soil or groundwater affected by, environmental pollution; and the clearing and grading of land.

AB770,10,13 2. Financing costs, including all interest paid to holders of evidences of indebtedness issued to pay for project costs and any premium paid over the principal amount of the obligations because of the redemption of the obligations prior to maturity.

AB770,10,15 3. Professional service costs, including costs incurred for architectural, planning, engineering, and legal advice and services.

AB770,10,17 4. Imputed administrative costs, including reasonable charges for the time spent by the owner or tenant in connection with the implementation of the project.

AB770,11,2 5. Costs related to the construction or alteration of sewerage treatment plants, water treatment plants or other environmental protection devices, storm or sanitary sewer lines, water lines, or amenities on streets; the relocation of utility lines or other utility infrastructure, including any lines or infrastructure related to an electric utility, natural gas utility, or telecommunications utility; the installation of infrastructure necessary to provide utility service to the property, including any service from an electric utility, natural gas utility, or telecommunications utility; or the rebuilding or expansion of streets if such costs are required by the applicable municipality and are not paid for by the municipality.

AB770,4 Section 4. 32.19 (4m) (a) (intro.) of the statutes is amended to read:

AB770,11,20 32.19 (4m) (a) Owner-occupied business or farm operation. (intro.) In addition to amounts otherwise authorized by this subchapter, the condemnor shall make a payment, not to exceed $50,000 $100,000, to any owner displaced person who has owned and occupied the business operation, or owned the farm operation, for not less than one year prior to the initiation of negotiations for the acquisition of the real property on which the business or farm operation lies, and who actually purchases a comparable replacement business or farm operation for the acquired property within 2 years after the date the person vacates the acquired property or receives payment from the condemnor, whichever is later. An owner displaced person who has owned and occupied the business operation, or owned the farm operation, for not less than one year prior to the initiation of negotiations for the acquisition of the real property on which the business or farm operation lies may elect to receive the payment under par. (b) 1. in lieu of the payment under this paragraph, but the amount of payment under par. (b) 1. to such an owner displaced person may not exceed the amount the owner displaced person is eligible to receive under this paragraph. The additional payment under this paragraph shall include the following amounts:

AB770,5 Section 5. 32.19 (4m) (a) 4. of the statutes is created to read:

AB770,11,23 32.19 (4m) (a) 4. Any reasonable project costs incurred or to be incurred by the displaced person.

AB770,6 Section 6. 32.19 (4m) (b) 1. of the statutes is amended to read:

AB770,12,9 32.19 (4m) (b) 1. The amount, not to exceed $30,000, which $80,000, that is necessary to lease or rent a comparable replacement business or farm operation for a period of 4 years, plus any reasonable project costs incurred or to be incurred by the tenant displaced person. The rental payment shall be computed by determining the average monthly rent paid for the property from which the person was displaced for the 12 months prior to the initiation of negotiations or, if displacement is not a direct result of acquisition, such other event as determined by the department of administration and the monthly rent of a comparable replacement business or farm operation, and multiplying the difference by 48; or

AB770,7 Section 7. 32.20 of the statutes is amended to read:

AB770,13,5 32.20 Procedure for collection of itemized items of compensation. Claims for damages itemized in ss. 32.19 and 32.195 shall be filed with the condemnor carrying on the project through which condemnee's or claimant's claims arise. All such claims must be filed after the damages upon which they are based have fully materialized but not later than 2 years after the condemnor takes physical possession of the entire property acquired or such other event as determined by the department of administration by rule. If such claim is not allowed within 90 days after the filing thereof, the claimant has a right of action against the condemnor carrying on the project through which the claim arises. Such action shall be commenced in a court of record in the county wherein the damages occurred. In causes of action, involving any state commission, board or other agency, excluding counties, the sum recovered by the claimant shall be paid out of any funds appropriated to such condemning agency. Any judgment shall be appealable by either party and any amount recovered by the body against which the claim was filed, arising from costs, counterclaims, punitive damages or otherwise may be used as an offset to any amount owed by it to the claimant, or may be collected in the same manner and form as any other judgment. The court shall award litigation expenses, as defined in s. 32.28 (1), to a claimant if the award of damages for the claimant exceeds the amount of damages initially allowed by the condemnor by 15 percent in an action under this section.

AB770,8 Section 8. 62.23 (7) (d) 2m. a. of the statutes is amended to read:

AB770,13,17 62.23 (7) (d) 2m. a. In case of a protest against an amendment proposed under subd. 2., duly signed and acknowledged by the owners of 20 percent or more either of the areas of the land included in such the proposed amendment, or by the owners of 20 percent or more of the area of the land that is immediately adjacent extending 100 feet therefrom from areas of the land included in the proposed amendment and that is located within the city, or by the owners of 20 percent or more of the land that is directly opposite thereto to areas of the land included in the proposed amendment extending 100 feet from the street frontage of such opposite land , such and that is located within the city, the amendment shall may not become effective except by the favorable vote of three-fourths a majority of the members of the council voting on the proposed change.

AB770,9 Section 9. 66.0104 (2) (h) of the statutes is created to read:

AB770,13,20 66.0104 (2) (h) 1. No city, village, or town may regulate the size of a bedroom in a rental unit.

AB770,13,22 2. No city, village, or town may impose any requirement related to the number of bedrooms in a rental unit.

AB770,10 Section 10. 66.0602 (3) (m) of the statutes is created to read:

AB770,14,2 66.0602 (3) (m) The levy increase limit otherwise applicable under this section to a city or village in the current year is increased by $1,000 for each new single-family residential dwelling unit for which a city or village issues an occupancy permit in the preceding year and that is all of the following:

AB770,14,3 1. Located on a parcel of no more than 0.25 acre.

AB770,14,5 2. Sold in the preceding year for not more than 80 percent of the median price of a new residential dwelling unit in the city or village in the preceding year.

AB770,11 Section 11. 66.0617 (2) (a) of the statutes is amended to read:

AB770,14,11 66.0617 (2) (a) A municipality may enact an ordinance under this section that imposes impact fees on developers to pay for the capital costs that are necessary to accommodate land development. A developer may pay fees imposed under this paragraph by maintaining in force a bond or irrevocable letter of credit in the amount of the fee imposed executed in the name of the municipality.

AB770,12 Section 12. 66.0617 (6) (am) of the statutes is created to read:

AB770,14,15 66.0617 (6) (am) May not include amounts for an increase in service capacity greater than the capacity necessary to serve the development for which the fee is imposed.

AB770,13 Section 13. 66.0617 (6) (fm) of the statutes is created to read:

AB770,14,18 66.0617 (6) (fm) May not include expenses for operation or maintenance of a public facility.

AB770,14 Section 14. 66.0617 (6) (g) of the statutes is amended to read:

AB770,14,23 66.0617 (6) (g) Shall be payable by the developer or the property owner to the municipality in full upon the issuance of a building permit by the municipality or 6 months before costs to construct, expand, or improve public facilities related to the development are actually incurred, whichever is later.