AB509: Bill Text

AB509,17,7 3. Any individual employed on a project of public works that is subject to this section who knowingly allows a contractor, subcontractor, or contractor's or subcontractor's agent to pay him or her less than the prevailing wage rate set forth in the contract governing the project, who gives up, waives, or returns any part of the compensation to which he or she is entitled under the contract, or who gives up, waives, or returns any part of the compensation to which he or she is normally entitled for work on a project that is not subject to this section during a week in which the individual works both on a project of public works that is subject to this section and on a project that is not subject to this section, is guilty of an offense under s. 946.15 (2).

AB509,17,13 4. Whoever induces any individual who seeks to be or is employed on any project of public works that is subject to this section to allow any part of the wages to which the individual is entitled under the contract governing the project to be deducted from the individual's pay is guilty of an offense under s. 946.15 (3), unless the deduction would be allowed under 29 CFR 3.5 or 3.6 from an individual who is working on a project that is subject to 40 USC 3142.

AB509,17,19 5. Any individual who is employed on a project of public works that is subject to this section who knowingly allows any part of the wages to which he or she is entitled under the contract governing the project to be deducted from his or her pay is guilty of an offense under s. 946.15 (4), unless the deduction would be allowed under 29 CFR 3.5 or 3.6 from an individual who is working on a project that is subject to 40 USC 3142.

AB509,17,22 6. Subdivision 1. does not apply to any person who fails to provide any information to the department to assist the department in determining prevailing wage rates under sub. (3) (am) or (ar).

AB509,18,10 (12) Debarment. (a) Except as provided under pars. (b) and (c), the department shall notify any local governmental unit applying for a determination under sub. (3) of the names of all persons that the department has found to have failed to pay the prevailing wage rate determined under sub. (3) or has found to have paid less than 1.5 times the hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor at any time in the preceding 3 years. The department shall include with each name the address of the person and shall specify when the person failed to pay the prevailing wage rate and when the person paid less than 1.5 times the hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor. A local governmental unit may not award any contract to the person unless otherwise recommended by the department or unless 3 years have elapsed from the date the department issued its findings or the date of final determination by a court of competent jurisdiction, whichever is later.

AB509,18,16 (b) The department may not include in a notification under par. (a) the name of any person on the basis of having subcontracted a contract for a project of public works to a person that the department has found to have failed to pay the prevailing wage rate determined under sub. (3) or has found to have paid less than 1.5 times the hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor.

AB509,18,20 (c) This subsection does not apply to any contractor, subcontractor, or agent who in good faith commits a minor violation of this section, as determined on a case-by-case basis through administrative hearings with all rights to due process afforded to all parties or who has not exhausted or waived all appeals.

AB509,19,5 (d) Any person submitting a bid or negotiating a contract on a project of public works that is subject to this section shall, on the date the person submits the bid or negotiates the contract, identify any construction business in which the person, or a shareholder, officer, or partner of the person, if the person is a business, owns, or has owned at least a 25 percent interest on the date the person submits the bid or negotiates the contract or at any other time within 3 years preceding the date the person submits the bid or negotiates the contract, if the business has been found to have failed to pay the prevailing wage rate determined under sub. (3) or to have paid less than 1.5 times the hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor.

AB509,19,6 (e) The department shall promulgate rules to administer this subsection.

AB509,10 Section 10 . 84.41 (3) of the statutes is created to read:

AB509,19,12 84.41 (3) Employment regulations. Employment regulations set forth in s. 103.50 pertaining to wages and hours shall apply to all projects constructed under s. 84.40 in the same manner as such laws apply to projects on other state highways. Where applicable, the federal wages and hours law known as the Davis-Bacon act shall apply.

AB509,11 Section 11 . 84.54 of the statutes is repealed.

AB509,12 Section 12 . 86.51 of the statutes is repealed.

AB509,13 Section 13 . 103.005 (12) (a) of the statutes is amended to read:

AB509,20,2 103.005 (12) (a) If any employer, employee, owner, or other person violates chs. 103 to 106, or fails or refuses to perform any duty required under chs. 103 to 106, within the time prescribed by the department, for which no penalty has been specifically provided, or fails, neglects or refuses to obey any lawful order given or made by the department or any judgment or decree made by any court in connection with chs. 103 to 106, for each such violation, failure or refusal, the employer, employee, owner or other person shall forfeit not less than $10 nor more than $100 for each offense. This paragraph does not apply to any person that fails to provide any information to the department to assist the department in determining prevailing wage rates or prevailing hours of labor under s. 103.49 (3) (a) or (am) or 103.50 (3) or (4).

AB509,14 Section 14 . 103.49 of the statutes is created to read:

AB509,20,4 103.49 Wage rate on state work. (1) Definitions. In this section:

AB509,20,13 (a) “Area" means the county in which a proposed project of public works that is subject to this section is located or, if the department determines that there is insufficient wage data in that county, “area" means those counties that are contiguous to that county or, if the department determines that there is insufficient wage data in those counties, “area" means those counties that are contiguous to those counties or, if the department determines that there is insufficient wage data in those counties, “area" means the entire state or, if the department is requested to review a determination under sub. (3) (c), “area" means the city, village, or town in which a proposed project of public works that is subject to this section is located.

AB509,20,19 (am) “Bona fide economic benefit" means an economic benefit for which an employer makes irrevocable contributions to a trust or fund created under 29 USC 186 (c) or to any other bona fide plan, trust, program, or fund no less often than quarterly or, if an employer makes annual contributions to such a bona fide plan, trust, program, or fund, for which the employer irrevocably escrows moneys at least quarterly based on the employer's expected annual contribution.

AB509,20,23 (b) “Hourly basic rate of pay" means the hourly wage paid to any employee, excluding any contributions or payments for health insurance benefits, vacation benefits, pension benefits, and any other bona fide economic benefits, whether paid directly or indirectly.

AB509,21,3 (bg) “Insufficient wage data" means less than 500 hours of work performed in a particular trade or occupation on projects that are similar to a proposed project of public works that is subject to this section.

AB509,21,9 (bj) “Minor service or maintenance work" means a project of public works that is limited to minor crack filling, chip or slurry sealing, or other minor pavement patching, not including overlays, that has a projected life span of no longer than 5 years; cleaning of drainage or sewer ditches or structures; or any other limited, minor work on public facilities or equipment that is routinely performed to prevent breakdown or deterioration.

AB509,21,12 (br) “Multiple-trade project of public works" means a project of public works in which no single trade accounts for 85 percent or more of the total labor cost of the project.

AB509,21,15 (c) “Prevailing hours of labor" for any trade or occupation in any area means 10 hours per day and 40 hours per week and may not include any hours worked on a Saturday or Sunday or on any of the following holidays:

AB509,21,16 1. January 1.

AB509,21,17 2. The last Monday in May.

AB509,21,18 3. July 4.

AB509,21,19 4. The first Monday in September.

AB509,21,20 5. The 4th Thursday in November.

AB509,21,21 6. December 25.

AB509,21,22 7. The day before if January 1, July 4, or December 25 falls on a Saturday.

AB509,21,23 8. The day following if January 1, July 4, or December 25 falls on a Sunday.

AB509,22,4 (d) 1. Except as provided in subd. 2., “prevailing wage rate" for any trade or occupation engaged in the erection, construction, remodeling, repairing, or demolition of any project of public works in any area means the hourly basic rate of pay, plus the hourly contribution for health insurance benefits, vacation benefits, pension benefits, and any other bona fide economic benefit, paid directly or indirectly for a majority of the hours worked in the trade or occupation on projects in the area.

AB509,22,14 2. If there is no rate at which a majority of the hours worked in the trade or occupation on projects in the area is paid, “prevailing wage rate" for any trade or occupation engaged in the erection, construction, remodeling, repairing, or demolition of any project of public works in any area means the average hourly basic rate of pay, weighted by the number of hours worked, plus the average hourly contribution, weighted by the number of hours worked, for health insurance benefits, vacation benefits, pension benefits, and any other bona fide economic benefit, paid directly or indirectly for all hours worked at the hourly basic rate of pay of the highest-paid 51 percent of hours worked in that trade or occupation on projects in that area.

AB509,22,17 (em) “Single-trade project of public works" means a project of public works in which a single trade accounts for 85 percent or more of the total labor cost of the project.

AB509,22,23 (f) “State agency" means any office, department, independent agency, institution of higher education, association, society, or other body in state government created or authorized to be created by the constitution or any law, including the legislature and the courts. “State agency" also includes the University of Wisconsin Hospitals and Clinics Authority, the Fox River Navigational System Authority, and the Wisconsin Aerospace Authority.

AB509,23,3 (fm) “Supply and installation contract" means a contract under which the material is installed by the supplier, the material is installed by means of simple fasteners or connectors such as screws or nuts and bolts, and no other work is performed on the site of the project of public works, and the total labor cost to install the material does not exceed 20 percent of the total cost of the contract.

AB509,23,4 (g) “Truck driver" includes an owner-operator of a truck.

AB509,23,7 (1m) Applicability. Subject to sub. (3g), this section applies to any project of public works erected, constructed, repaired, remodeled, or demolished for the state or a state agency, including all of the following:

AB509,23,10 (a) A project erected, constructed, repaired, remodeled, or demolished by one state agency for another state agency under any contract or under any statute specifically authorizing cooperation between state agencies.

AB509,23,14 (b) A project in which the completed facility is leased, purchased, lease purchased, or otherwise acquired by, or dedicated to, the state in lieu of the state or a state agency contracting for the erection, construction, repair, remodeling, or demolition of the facility.

AB509,23,17 (c) A sanitary sewer or water main project in which the completed sanitary sewer or water main is acquired by, or dedicated to, the state for ownership or maintenance by the state.

AB509,24,14 (2) Prevailing wage rates and hours of labor. Any contract made for the erection, construction, remodeling, repairing, or demolition of any project of public works to which the state or any state agency is a party shall contain a stipulation that no individual performing the work described in sub. (2m) may be allowed to work a greater number of hours per day or per week than the prevailing hours of labor, except that any such individual may be allowed or required to work more than such prevailing hours of labor per day and per week if he or she is paid for all hours worked in excess of the prevailing hours of labor at a rate of at least 1.5 times his or her hourly basic rate of pay; nor may he or she be paid less than the prevailing wage rate determined under sub. (3) in the same or most similar trade or occupation in the area in which the project of public works is situated. The notice published for the purpose of securing bids for the project must contain a reference to the prevailing wage rates determined under sub. (3) and the prevailing hours of labor. Except as otherwise provided in this subsection, if any contract or subcontract for a project of public works that is subject to this section is entered into, the prevailing wage rates determined under sub. (3) and the prevailing hours of labor shall be physically incorporated into and made a part of the contract or subcontract. For a minor subcontract, as determined by the department, the department shall prescribe by rule the method of notifying the minor subcontractor of the prevailing wage rates and prevailing hours of labor applicable to the minor subcontract. The prevailing wage rates and prevailing hours of labor applicable to a contract or subcontract may not be changed during the time that the contract or subcontract is in force.

AB509,24,20 (2m) Covered employees. (a) Subject to par. (b), any person subject to this section shall pay all of the following employees the prevailing wage rate determined under sub. (3) and may not allow such employees to work a greater number of hours per day or per week than the prevailing hours of labor, unless the person pays for all hours worked in excess of the prevailing hours of labor at a rate of at least 1.5 times the employees' hourly basic rate of pay:

AB509,24,22 1. All laborers, workers, mechanics, and truck drivers employed on the site of a project of public works that is subject to this section.

AB509,25,3 2. All laborers, workers, mechanics, and truck drivers employed in the manufacturing or furnishing of materials, articles, supplies, or equipment on the site of a project of public works that is subject to this section or from a facility dedicated exclusively, or nearly so, to a project of public works that is subject to this section by a contractor, subcontractor, agent, or other person performing any work on the site of the project.

AB509,25,11 (b) A laborer, worker, mechanic, or truck driver who is employed to process, manufacture, pick up, or deliver materials or products from a commercial establishment that has a fixed place of business from which the establishment supplies processed or manufactured materials or products or from a facility that is not dedicated exclusively, or nearly so, to a project of public works that is subject to this section is not entitled to receive the prevailing wage rate determined under sub. (3) or to receive at least 1.5 times his or her hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor unless any of the following applies:

AB509,25,16 1. The laborer, worker, mechanic, or truck driver is employed to go to the source of mineral aggregate such as sand, gravel, or stone and deliver that mineral aggregate to the site of a project of public works that is subject to this section by depositing the material directly in final place, from the transporting vehicle or through spreaders from the transporting vehicle.

AB509,25,20 2. The laborer, worker, mechanic, or truck driver is employed to go to the site of a project that is subject to this section, pick up excavated material or spoil from the site of the project of public works, and transport that excavated material or spoil away from the site of the project.

AB509,25,23 (c) A person that is subject to this section shall pay a truck driver who is an owner-operator of a truck separately for his or her work and for the use of his or her truck.

AB509,26,14 (3) Investigation; determination. (a) Before a state agency issues a request for bids for any work to which this section applies, the state agency having the authority to prescribe the specifications shall apply to the department to determine the prevailing wage rate for each trade or occupation required in the work under contemplation in the area in which the work is to be done. The department shall conduct investigations and hold public hearings as necessary to define the trades or occupations that are commonly employed on projects that are subject to this section and to inform itself of the prevailing wage rates in all areas of the state for those trades or occupations, in order to determine the prevailing wage rate for each trade or occupation. The department shall issue its determination within 30 days after receiving the request and shall file the determination with the requesting state agency. A state agency that has contracted for a project of public works subject to this section shall post the prevailing wage rates determined by the department, the prevailing hours of labor, and the provisions of subs. (2) and (6m) in at least one conspicuous place on the site of the project that is easily accessible by employees working on the project.

AB509,26,21 (am) The department shall, by January 1 of each year, compile the prevailing wage rates for each trade or occupation in each area. The compilation shall, in addition to the current prevailing wage rates, include future prevailing wage rates when those prevailing wage rates can be determined for any trade or occupation in any area and shall specify the effective date of those future prevailing wage rates. If a project of public works extends into more than one area, the department shall determine only one standard of prevailing wage rates for the entire project.

AB509,27,5 (ar) In determining prevailing wage rates under par. (a) or (am), the department may not use data from projects that are subject to this section, s. 66.0903, 103.50, or 229.8275, or 40 USC 3142 unless the department determines that there is insufficient wage data in the area to determine those prevailing wage rates, in which case the department may use data from projects that are subject to this section, s. 66.0903, 103.50, or 229.8275, or 40 USC 3142. In determining prevailing wage rates under par. (a) or (am), the department may not use data from any construction work performed by a state agency or a local governmental unit, as defined in s. 66.0903 (1) (d).

AB509,27,14 (b) Any person may request a recalculation of any portion of an initial determination within 30 days after the initial determination date if the person submits evidence with the request showing that the prevailing wage rate for any given trade or occupation included in the initial determination does not represent the prevailing wage rate for that trade or occupation in the area. The evidence shall include wage rate information reflecting work performed by individuals working in the contested trade or occupation in the area during the current survey period. The department shall affirm or modify the initial determination within 15 days after the date on which the department receives the request for recalculation.

AB509,28,3 (c) In addition to the recalculation under par. (b), the state agency that requested the determination under this subsection may request a review of any portion of a determination within 30 days after the date of issuance of the determination if the state agency submits evidence with the request showing that the prevailing wage rate for any given trade or occupation included in the determination does not represent the prevailing wage rate for that trade or occupation in the city, village, or town in which the proposed project of public works is located. That evidence shall include wage rate information for the contested trade or occupation on at least 3 similar projects located in the city, village, or town where the proposed project of public works is located on which some work has been performed during the current survey period and that were considered by the department in issuing its most recent compilation under par. (am). The department shall affirm or modify the determination within 15 days after the date on which the department receives the request for review.

AB509,28,4 (3g) Nonapplicability. This section does not apply to any of the following:

AB509,28,7 (a) A single-trade project of public works for which the estimated project cost of completion is less than $48,000 or a multiple-trade project of public works for which the estimated project cost of completion is less than $100,000.

AB509,28,11 (b) Work performed on a project of public works for which the state or the state agency contracting for the project is not required to compensate any contractor, subcontractor, contractor's or subcontractor's agent, or individual for performing the work.

AB509,28,13 (c) Minor service or maintenance work, warranty work, or work under a supply and installation contract.

AB509,28,14 (f) A public highway, street, or bridge project.

AB509,28,17 (g) A project of public works involving the erection, construction, repair, remodeling, or demolition of a residential property containing 2 dwelling units or less.

AB509,28,22 (h) A road, street, bridge, sanitary sewer, or water main project that is a part of a development in which not less than 90 percent of the lots contain or will contain 2 dwelling units or less, as determined by the local governmental unit at the time of approval of the development, and that, on completion, is acquired by, or dedicated to, the state for ownership or maintenance by the state.

AB509,29,5 (4r) Compliance. (a) When the department finds that a state agency has not requested a determination under sub. (3) (a) or that a state agency, contractor, or subcontractor has not physically incorporated a determination into a contract or subcontract as required under sub. (2) or has not notified a minor subcontractor of a determination in the manner prescribed by the department by rule promulgated under sub. (2), the department shall notify the state agency, contractor, or subcontractor of the noncompliance and shall file the determination with the state agency, contractor, or subcontractor within 30 days after the notice.

AB509,29,10 (b) Upon completion of a project of public works and before receiving final payment for his or her work on the project, each agent or subcontractor shall furnish the contractor with an affidavit stating that the agent or subcontractor has complied fully with the requirements of this section. A contractor may not authorize final payment until the affidavit is filed in proper form and order.

AB509,29,24 (c) Upon completion of a project of public works and before receiving final payment for his or her work on the project, each contractor shall file with the state agency authorizing the work an affidavit stating that the contractor has complied fully with the requirements of this section and that the contractor has received an affidavit under par. (b) from each of the contractor's agents and subcontractors. A state agency may not authorize a final payment until the affidavit is filed in proper form and order. If a state agency authorizes a final payment before an affidavit is filed in proper form and order or if the department determines, based on the greater weight of the credible evidence, that any person performing the work specified in sub. (2m) has been or may have been paid less than the prevailing wage rate or less than 1.5 times the hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor and requests that the state agency withhold all or part of the final payment, but the state agency fails to do so, the state agency is liable for all back wages payable up to the amount of the final payment.

AB509,30,6 (5) Records; inspection; enforcement. (a) Each contractor, subcontractor, or contractor's or subcontractor's agent that performs work on a project of public works that is subject to this section shall keep full and accurate records clearly indicating the name and trade or occupation of every individual performing the work described in sub. (2m) and an accurate record of the number of hours worked by each of those individuals and the actual wages paid for the hours worked.

AB509,30,17 (b) The department shall enforce this section. The department may demand and examine, and every contractor, subcontractor, and contractor's and subcontractor's agent shall keep, and furnish upon request by the department, copies of payrolls and other records and information relating to the wages paid to individuals performing the work described in sub. (2m) for work to which this section applies. The department may inspect records in the manner provided in this chapter. Every contractor, subcontractor, or agent performing work on a project of public works that is subject to this section is subject to the requirements of this chapter relating to the examination of records. Section 111.322 (2m) applies to discharge and other discriminatory acts arising in connection with any proceeding under this section.

AB509,31,5 (c) If requested by any person, the department shall inspect the payroll records of any contractor, subcontractor, or agent performing work on a project of public works that is subject to this section as provided in this paragraph to ensure compliance with this section. On receipt of such a request, the department shall request that the contractor, subcontractor, or agent submit to the department a certified record of the information specified in par. (a), other than personally identifiable information relating to an employee of the contractor, subcontractor, or agent, for no longer than a 4-week period. The department may request a contractor, subcontractor, or agent to submit those records no more than once per calendar quarter for each project of public works on which the contractor, subcontractor, or agent is performing work. The department may not charge a requester a fee for obtaining that information. Certified records submitted to the department under this paragraph are open for public inspection and copying under s. 19.35 (1).

AB509,31,12 (6m) Liability and penalties. (ag) 1. A contractor, subcontractor, or contractor's or subcontractor's agent who fails to pay the prevailing wage rate determined by the department under sub. (3) or who pays less than 1.5 times the hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor is liable to any affected employee in the amount of his or her unpaid wages or his or her unpaid overtime compensation and in an additional amount as liquidated damages as provided in subd. 2. or 3., whichever is applicable.

AB509,31,21 2. If the department determines upon inspection under sub. (5) (b) or (c) that a contractor, subcontractor, or contractor's or subcontractor's agent has failed to pay the prevailing wage rate determined by the department under sub. (3) or has paid less than 1.5 times the hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor, the department shall order the contractor to pay to any affected employee the amount of his or her unpaid wages or his or her unpaid overtime compensation and an additional amount equal to 100 percent of the amount of those unpaid wages or that unpaid overtime compensation as liquidated damages within a period specified by the department in the order.

AB509,32,7 3. In addition to or in lieu of recovering the liability specified in subd. 1. as provided in subd. 2., any employee for and on behalf of that employee and other employees similarly situated may commence an action to recover that liability in any court of competent jurisdiction. If the court finds that a contractor, subcontractor, or contractor's or subcontractor's agent has failed to pay the prevailing wage rate determined by the department under sub. (3) or has paid less than 1.5 times the hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor, the court shall order the contractor, subcontractor, or agent to pay to any affected employee the amount of his or her unpaid wages or his or her unpaid overtime compensation and an additional amount equal to 100 percent of the amount of those unpaid wages or that unpaid overtime compensation as liquidated damages.

AB509,32,12 5. No employee may be a party plaintiff to an action under subd. 3. unless the employee consents in writing to become a party and the consent is filed in the court in which the action is brought. Notwithstanding s. 814.04 (1), the court shall, in addition to any judgment awarded to the plaintiff, allow reasonable attorney fees and costs to be paid by the defendant.

AB509,32,16 (am) Except as provided in pars. (b), (d), and (f), any contractor, subcontractor, or contractor's or subcontractor's agent who violates this section may be fined not more than $200 or imprisoned for not more than 6 months or both. Each day that a violation continues is a separate offense.

AB509,32,25 (b) Whoever induces an individual who seeks to be or is employed on any project of public works that is subject to this section to give up, waive, or return any part of the wages to which the individual is entitled under the contract governing the project, or who reduces the hourly basic rate of pay normally paid to an individual for work on a project that is not subject to this section during a week in which the individual works both on a project of public works that is subject to this section and on a project that is not subject to this section, by threat not to employ, by threat of dismissal from employment, or by any other means is guilty of an offense under s. 946.15 (1).

AB509,33,10 (c) Any individual who is employed on a project of public works that is subject to this section who knowingly allows a contractor, subcontractor, or contractor's or subcontractor's agent to pay him or her less than the prevailing wage rate set forth in the contract governing the project, who gives up, waives, or returns any part of the compensation to which he or she is entitled under the contract, or who gives up, waives, or returns any part of the compensation to which he or she is normally entitled for work on a project that is not subject to this section during a week in which the individual works both on a project of public works that is subject to this section and on a project that is not subject to this section, is guilty of an offense under s. 946.15 (2).

AB509,33,16 (d) Whoever induces any individual who seeks to be or is employed on any project of public works that is subject to this section to allow any part of the wages to which the individual is entitled under the contract governing the project to be deducted from the individual's pay is guilty of an offense under s. 946.15 (3), unless the deduction would be allowed under 29 CFR 3.5 or 3.6 from an individual who is working on a project that is subject to 40 USC 3142.

AB509,33,22 (e) Any individual who is employed on a project of public works that is subject to this section who knowingly allows any part of the wages to which he or she is entitled under the contract governing the project to be deducted from his or her pay is guilty of an offense under s. 946.15 (4), unless the deduction would be allowed under 29 CFR 3.5 or 3.6 from an individual who is working on a project that is subject to 40 USC 3142.

AB509,33,25 (f) Paragraph (am) does not apply to any person who fails to provide any information to the department to assist the department in determining prevailing wage rates under sub. (3) (a) or (am).

AB509,34,12 (7) Debarment. (a) Except as provided under pars. (b) and (c), the department shall distribute to all state agencies a list of all persons that the department has found to have failed to pay the prevailing wage rate determined under sub. (3) or has found to have paid less than 1.5 times the hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor at any time in the preceding 3 years. The department shall include with any name the address of the person and shall specify when the person failed to pay the prevailing wage rate and when the person paid less than 1.5 times the hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor. A state agency may not award any contract to the person unless otherwise recommended by the department or unless 3 years have elapsed from the date the department issued its findings or date of final determination by a court of competent jurisdiction, whichever is later.

AB509,34,18 (b) The department may not include in a notification under par. (a) the name of any person on the basis of having subcontracted a contract for a project of public works to a person that the department has found to have failed to pay the prevailing wage rate determined under sub. (3) or has found to have paid less than 1.5 times the hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor.

AB509,34,22 (c) This subsection does not apply to any contractor, subcontractor, or agent who in good faith commits a minor violation of this section, as determined on a case-by-case basis through administrative hearings with all rights to due process afforded to all parties or who has not exhausted or waived all appeals.

AB509,35,6 (d) Any person submitting a bid on a project of public works that is subject to this section shall, on the date the person submits the bid, identify any construction business in which the person, or a shareholder, officer, or partner of the person if the person is a business, owns or has owned at least a 25 percent interest on the date the person submits the bid or at any other time within 3 years preceding the date the person submits the bid, if the business has been found to have failed to pay the prevailing wage rate determined under sub. (3) or to have paid less than 1.5 times the hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor.

AB509,35,7 (e) The department shall promulgate rules to administer this subsection.

AB509,15 Section 15 . 103.50 of the statutes is created to read:

AB509,35,9 103.50 Highway contracts. (1) Definitions. In this section:

AB509,35,16 (a) “Area" means the county in which a proposed project that is subject to this section is located or, if the department determines that there is insufficient wage data in that county, “area" means those counties that are contiguous to that county or, if the department determines that there is insufficient wage data in those counties, “area" means those counties that are contiguous to those counties or, if the department determines that there is insufficient wage data in those counties, “area" means the entire state.

AB509,35,17 (b) “Hourly basic rate of pay" has the meaning given in s. 103.49 (1) (b).

AB509,35,18 (bg) “Insufficient wage data" has the meaning given in s. 103.49 (1) (bg).

AB509,35,19 (c) “Prevailing hours of labor" has the meaning given in s. 103.49 (1) (c).