Amendment SA6-AB64

AB64-SA6,30,15 (c) If requested by any person, the department shall inspect the payroll records of any contractor, subcontractor, or agent performing work on a project of public works that is subject to this section as provided in this paragraph to ensure compliance with this section. On receipt of such a request, the department shall request the contractor, subcontractor, or agent to submit to the department a certified record of the information specified in par. (a), other than personally identifiable information relating to an employee of the contractor, subcontractor, or agent, for no longer than a 4-week period. The department may request a contractor, subcontractor, or agent to submit those records no more than once per calendar quarter for each project of public works on which the contractor, subcontractor, or agent is performing work. The department may not charge a requester a fee for obtaining that information. The department shall make available for public inspection certified records submitted to the department under this paragraph.

AB64-SA6,30,22 (6m) Liability and penalties. (ag) 1. Any contractor, subcontractor, or contractor's or subcontractor's agent who fails to pay the prevailing wage rate determined by the department under sub. (3) or who pays less than 1.5 times the hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor is liable to any affected employee in the amount of his or her unpaid wages or his or her unpaid overtime compensation and in an additional amount as liquidated damages as provided in subd. 2. or 3., whichever is applicable.

AB64-SA6,31,6 2. If the department determines upon inspection under sub. (5) (b) or (c) that a contractor, subcontractor, or contractor's or subcontractor's agent has failed to pay the prevailing wage rate determined by the department under sub. (3) or has paid less than 1.5 times the hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor, the department shall order the contractor to pay to any affected employee the amount of his or her unpaid wages or his or her unpaid overtime compensation and an additional amount equal to 100 percent of the amount of those unpaid wages or that unpaid overtime compensation as liquidated damages within a period specified by the department in the order.

AB64-SA6,31,17 3. In addition to or in lieu of recovering the liability specified in subd. 1. as provided in subd. 2., any employee for and in behalf of that employee and other employees similarly situated may commence an action to recover that liability in any court of competent jurisdiction. If the court finds that a contractor, subcontractor, or contractor's or subcontractor's agent has failed to pay the prevailing wage rate determined by the department under sub. (3) or has paid less than 1.5 times the hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor, the court shall order the contractor, subcontractor, or agent to pay to any affected employee the amount of his or her unpaid wages or his or her unpaid overtime compensation and an additional amount equal to 100 percent of the amount of those unpaid wages or that unpaid overtime compensation as liquidated damages.

AB64-SA6,31,22 5. No employee may be a party plaintiff to an action under subd. 3. unless the employee consents in writing to become a party and the consent is filed in the court in which the action is brought. Notwithstanding s. 814.04 (1), the court shall, in addition to any judgment awarded to the plaintiff, allow reasonable attorney fees and costs to be paid by the defendant.

AB64-SA6,32,2 (am) Except as provided in pars. (b), (d), and (f), any contractor, subcontractor, or contractor's or subcontractor's agent who violates this section may be fined not more than $200 or imprisoned for not more than 6 months or both. Each day that a violation continues is a separate offense.

AB64-SA6,32,10 (b) Whoever induces any person who seeks to be or is employed on any project of public works that is subject to this section to give up, waive, or return any part of the wages to which the person is entitled under the contract governing the project, or who reduces the hourly basic rate of pay normally paid to a person for work on a project that is not subject to this section during a week in which the person works both on a project of public works that is subject to this section and on a project that is not subject to this section, by threat not to employ, by threat of dismissal from employment, or by any other means is guilty of an offense under s. 946.15 (1).

AB64-SA6,32,20 (c) Any person employed on a project of public works that is subject to this section who knowingly permits a contractor, subcontractor, or contractor's or subcontractor's agent to pay him or her less than the prevailing wage rate set forth in the contract governing the project, who gives up, waives, or returns any part of the compensation to which he or she is entitled under the contract, or who gives up, waives, or returns any part of the compensation to which he or she is normally entitled for work on a project that is not subject to this section during a week in which the person works both on a project of public works that is subject to this section and on a project that is not subject to this section, is guilty of an offense under s. 946.15 (2).

AB64-SA6,33,2 (d) Whoever induces any person who seeks to be or is employed on any project of public works that is subject to this section to permit any part of the wages to which the person is entitled under the contract governing the project to be deducted from the person's pay is guilty of an offense under s. 946.15 (3), unless the deduction would be permitted under 29 CFR 3.5 or 3.6 from a person who is working on a project that is subject to 40 USC 3142.

AB64-SA6,33,8 (e) Any person employed on a project of public works that is subject to this section who knowingly permits any part of the wages to which he or she is entitled under the contract governing the project to be deducted from his or her pay is guilty of an offense under s. 946.15 (4), unless the deduction would be permitted under 29 CFR 3.5 or 3.6 from a person who is working on a project that is subject to 40 USC 3142.

AB64-SA6,33,11 (f) Paragraph (am) does not apply to any person who fails to provide any information to the department to assist the department in determining prevailing wage rates under sub. (3) (a) or (am).

AB64-SA6,33,23 (7) Debarment. (a) Except as provided under pars. (b) and (c), the department shall distribute to all state agencies a list of all persons whom the department has found to have failed to pay the prevailing wage rate determined under sub. (3) or has found to have paid less than 1.5 times the hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor at any time in the preceding 3 years. The department shall include with any name the address of the person and shall specify when the person failed to pay the prevailing wage rate and when the person paid less than 1.5 times the hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor. A state agency may not award any contract to the person unless otherwise recommended by the department or unless 3 years have elapsed from the date the department issued its findings or date of final determination by a court of competent jurisdiction, whichever is later.

AB64-SA6,34,3 (b) The department may not include in a notification under par. (a) the name of any person on the basis of having let work to a person whom the department has found to have failed to pay the prevailing wage rate determined under sub. (3) or has found to have paid less than 1.5 times the hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor.

AB64-SA6,34,7 (c) This subsection does not apply to any contractor, subcontractor, or agent who in good faith commits a minor violation of this section, as determined on a case-by-case basis through administrative hearings with all rights to due process afforded to all parties or who has not exhausted or waived all appeals.

AB64-SA6,34,16 (d) Any person submitting a bid on a project of public works that is subject to this section shall, on the date the person submits the bid, identify any construction business in which the person, or a shareholder, officer, or partner of the person if the person is a business, owns or has owned at least a 25 percent interest on the date the person submits the bid or at any other time within 3 years preceding the date the person submits the bid, if the business has been found to have failed to pay the prevailing wage rate determined under sub. (3) or to have paid less than 1.5 times the hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor.

AB64-SA6,34,17 (e) The department shall promulgate rules to administer this subsection.

AB64-SA6,15 Section 15. 103.50 of the statutes is created to read:

AB64-SA6,34,19 103.50 Highway contracts. (1) Definitions. In this section:

AB64-SA6,35,2 (a) “Area" means the county in which a proposed project that is subject to this section is located or, if the department determines that there is insufficient wage data in that county, “area" means those counties that are contiguous to that county or, if the department determines that there is insufficient wage data in those counties, “area" means those counties that are contiguous to those counties or, if the department determines that there is insufficient wage data in those counties, “area" means the entire state.

AB64-SA6,35,3 (b) “Hourly basic rate of pay" has the meaning given in s. 103.49 (1) (b).

AB64-SA6,35,4 (bg) “Insufficient wage data" has the meaning given in s. 103.49 (1) (bg).

AB64-SA6,35,5 (c) “Prevailing hours of labor" has the meaning given in s. 103.49 (1) (c).

AB64-SA6,35,10 (d) 1. Except as provided in subd. 2., “prevailing wage rate" for any trade or occupation in any area means the hourly basic rate of pay, plus the hourly contribution for health insurance benefits, vacation benefits, pension benefits, and any other bona fide economic benefit, paid directly or indirectly, for a majority of the hours worked in the trade or occupation in the area.

AB64-SA6,35,17 2. If there is no rate at which a majority of the hours worked in the trade or occupation in the area is paid, “prevailing wage rate" means the average hourly basic rate of pay, weighted by the number of hours worked, plus the average hourly contribution, weighted by the number of hours worked, for health insurance benefits, vacation benefits, pension benefits, and any other bona fide economic benefit, paid directly or indirectly for all hours worked at the hourly basic rate of pay of the highest-paid 51 percent of hours worked in that trade or occupation in that area.

AB64-SA6,35,18 (e) “Truck driver" has the meaning given in s. 103.49 (1) (g).

AB64-SA6,36,4 (2) Prevailing wage rates and hours of labor. No person performing the work described in sub. (2m) in the employ of a contractor, subcontractor, agent, or other person performing any work on a project under a contract based on bids as provided in s. 84.06 (2) to which the state is a party for the construction or improvement of any highway may be permitted to work a greater number of hours per day or per week than the prevailing hours of labor; nor may he or she be paid a lesser rate of wages than the prevailing wage rate in the area in which the work is to be done determined under sub. (3); except that any such person may be permitted or required to work more than such prevailing hours of labor per day and per week if he or she is paid for all hours worked in excess of the prevailing hours of labor at a rate of at least 1.5 times his or her hourly basic rate of pay.

AB64-SA6,36,9 (2g) Nonapplicability. This section does not apply to a single-trade project of public works, as defined in s. 103.49 (1) (em), for which the estimated project cost of completion is less than $48,000 or a multiple-trade project of public works, as defined in s. 103.49 (1) (br), for which the estimated project cost of completion is less than $100,000.

AB64-SA6,36,14 (2m) Covered employees. (a) Subject to par. (b), all of the following employees shall be paid the prevailing wage rate determined under sub. (3) and may not be permitted to work a greater number of hours per day or per week than the prevailing hours of labor, unless they are paid for all hours worked in excess of the prevailing hours of labor at a rate of at least 1.5 times their hourly basic rate of pay:

AB64-SA6,36,16 1. All laborers, workers, mechanics, and truck drivers employed on the site of a project that is subject to this section.

AB64-SA6,36,21 2. All laborers, workers, mechanics, and truck drivers employed in the manufacturing or furnishing of materials, articles, supplies, or equipment on the site of a project that is subject to this section or from a facility dedicated exclusively, or nearly so, to a project that is subject to this section by a contractor, subcontractor, agent, or other person performing any work on the site of the project.

AB64-SA6,37,4 (b) A laborer, worker, mechanic, or truck driver who is employed to process, manufacture, pick up, or deliver materials or products from a commercial establishment that has a fixed place of business from which the establishment supplies processed or manufactured materials or products or from a facility that is not dedicated exclusively, or nearly so, to a project that is subject to this section is not entitled to receive the prevailing wage rate determined under sub. (3) or to receive at least 1.5 times his or her hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor unless any of the following applies:

AB64-SA6,37,9 1. The laborer, worker, mechanic, or truck driver is employed to go to the source of mineral aggregate such as sand, gravel, or stone and deliver that mineral aggregate to the site of a project that is subject to this section by depositing the material directly in final place, from the transporting vehicle or through spreaders from the transporting vehicle.

AB64-SA6,37,13 2. The laborer, worker, mechanic, or truck driver is employed to go to the site of a project that is subject to this section, pick up excavated material or spoil from the site of the project, and transport that excavated material or spoil away from the site of the project and return to the site of the project.

AB64-SA6,37,15 (c) A truck driver who is an owner-operator of a truck shall be paid separately for his or her work and for the use of his or her truck.

AB64-SA6,37,21 (3) Investigations; determinations. The department shall conduct investigations and hold public hearings necessary to define the trades or occupations that are commonly employed in the highway construction industry and to inform itself as to the prevailing wage rates in all areas of the state for those trades or occupations, in order to ascertain and determine the prevailing wage rates accordingly.

AB64-SA6,38,8 (4) Certification of prevailing wage rates. The department of workforce development shall, by May 1 of each year, certify to the department of transportation the prevailing wage rates in each area for all trades or occupations commonly employed in the highway construction industry. The certification shall, in addition to the current prevailing wage rates, include future prevailing wage rates when such prevailing wage rates can be determined for any such trade or occupation in any area and shall specify the effective date of those future prevailing wage rates. The certification shall also include wage rates for work performed on Sundays or the holidays specified in s. 103.49 (1) (c) and shift differentials based on the time of day or night when work is performed. If a construction project extends into more than one area, there shall be but one standard of prevailing wage rates for the entire project.

AB64-SA6,38,14 (4m) Wage rate data. In determining prevailing wage rates for projects that are subject to this section, the department shall use data from projects that are subject to this section, s. 66.0903 or 103.49, or 40 USC 3142. In determining prevailing wage rates for those projects, the department may not use data from any construction work that is performed by a state agency or a local governmental unit, as defined in s. 66.0903 (1) (d).

AB64-SA6,38,18 (5) Appeals to governor. If the department of transportation considers any determination of the department of workforce development as to the prevailing wage rates in an area to have been incorrect, it may appeal to the governor, whose determination shall be final.

AB64-SA6,39,9 (6) Contents of contracts. A reference to the prevailing wage rates determined under sub. (3) and the prevailing hours of labor shall be published in the notice issued for the purpose of securing bids for a project. If any contract or subcontract for a project that is subject to this section is entered into, the prevailing wage rates determined under sub. (3) and the prevailing hours of labor shall be physically incorporated into and made a part of the contract or subcontract, except that for a minor subcontract, as determined by the department of workforce development, that department shall prescribe by rule the method of notifying the minor subcontractor of the prevailing wage rates and prevailing hours of labor applicable to the minor subcontract. The prevailing wage rates and prevailing hours of labor applicable to a contract or subcontract may not be changed during the time that the contract or subcontract is in force. For the information of the employees working on the project, the prevailing wage rates determined by the department, the prevailing hours of labor, and the provisions of subs. (2) and (7) shall be kept posted by the department of transportation in at least one conspicuous and easily accessible place on the site of the project.

AB64-SA6,39,13 (7) Penalties. (a) Except as provided in pars. (b), (d), and (f), any contractor, subcontractor, or contractor's or subcontractor's agent who violates this section may be fined not more than $200 or imprisoned for not more than 6 months or both. Each day that a violation continues is a separate offense.

AB64-SA6,39,21 (b) Whoever induces any person who seeks to be or is employed on any project that is subject to this section to give up, waive, or return any part of the wages to which the person is entitled under the contract governing the project, or who reduces the hourly basic rate of pay normally paid to a person for work on a project that is not subject to this section during a week in which the person works both on a project that is subject to this section and on a project that is not subject to this section, by threat not to employ, by threat of dismissal from employment or by any other means is guilty of an offense under s. 946.15 (1).

AB64-SA6,40,5 (c) Any person employed on a project that is subject to this section who knowingly permits a contractor, subcontractor, or contractor's or subcontractor's agent to pay him or her less than the prevailing wage rate set forth in the contract governing the project, who gives up, waives, or returns any part of the compensation to which he or she is entitled under the contract, or who gives up, waives, or returns any part of the compensation to which he or she is normally entitled for work on a project that is not subject to this section during a week in which the person works both on a project that is subject to this section and on a project that is not subject to this section, is guilty of an offense under s. 946.15 (2).

AB64-SA6,40,11 (d) Whoever induces any person who seeks to be or is employed on any project that is subject to this section to permit any part of the wages to which the person is entitled under the contract governing the project to be deducted from the person's pay is guilty of an offense under s. 946.15 (3), unless the deduction would be permitted under 29 CFR 3.5 or 3.6 from a person who is working on a project that is subject to 40 USC 3142.

AB64-SA6,40,16 (e) Any person employed on a project that is subject to this section who knowingly permits any part of the wages to which he or she is entitled under the contract governing the project to be deducted from his or her pay is guilty of an offense under s. 946.15 (4), unless the deduction would be permitted under 29 CFR 3.5 or 3.6 from a person who is working on a project that is subject to 40 USC 3142.

AB64-SA6,40,19 (f) Paragraph (a) does not apply to any person who fails to provide any information to the department to assist the department in determining prevailing wage rates under sub. (3) or (4).

AB64-SA6,41,4 (8) Enforcement and prosecution. The department of transportation shall require adherence to subs. (2), (2m), and (6). The department of transportation may demand and examine, and every contractor, subcontractor, and contractor's or subcontractor's agent shall keep and furnish upon request by the department of transportation, copies of payrolls and other records and information relating to compliance with this section. Upon request of the department of transportation or upon complaint of alleged violation, the district attorney of the county in which the work is located shall investigate as necessary and prosecute violations in a court of competent jurisdiction. Section 111.322 (2m) applies to discharge and other discriminatory acts arising in connection with any proceeding under this section.

AB64-SA6,16 Section 16. 103.503 (1) (a) of the statutes is amended to read:

AB64-SA6,41,11 103.503 (1) (a) “Accident" means an incident caused, contributed to, or otherwise involving an employee that resulted or could have resulted in death, personal injury, or property damage and that occurred while the employee was performing the work described in s. 66.0903 (4), 2013 stats., or s. 16.856 103.49 (2m) on a project of public works or while the employee was performing work on a public utility project.

AB64-SA6,17 Section 17. 103.503 (1) (c) of the statutes is amended to read:

AB64-SA6,41,17 103.503 (1) (c) “Contracting agency" means a local governmental unit, as defined in s. 66.0903 (1) (d), or a state agency, as defined in s. 16.856 103.49 (1) (h) (f), that has contracted for the performance of work on a project of public works or a public utility that has contracted for the performance of work on a public utility project.

AB64-SA6,18 Section 18. 103.503 (1) (e) of the statutes is amended to read:

AB64-SA6,41,21 103.503 (1) (e) “Employee" means a laborer, worker, mechanic, or truck driver who performs the work described in s. 66.0903 (4), 2013 stats., or s. 16.856 103.49 (2m) on a project of public works or on a public utility project.

AB64-SA6,19 Section 19. 103.503 (1) (g) of the statutes is amended to read:

AB64-SA6,42,2 103.503 (1) (g) “Project of public works" means a project of public works that is subject to s. 16.856 or that would be subject to s. 66.0903, 2013 stats., if the project were erected, constructed, repaired, remodeled, or demolished prior to January 1, 2017 or 103.49.

AB64-SA6,20 Section 20. 103.503 (2) of the statutes is amended to read:

AB64-SA6,42,11 103.503 (2) Substance abuse prohibited. No employee may use, possess, attempt to possess, distribute, deliver, or be under the influence of a drug, or use or be under the influence of alcohol, while performing the work described in s. 66.0903 (4), 2013 stats., or s. 16.856 103.49 (2m) on a project of public works or while performing work on a public utility project. An employee is considered to be under the influence of alcohol for purposes of this subsection if he or she has an alcohol concentration that is equal to or greater than the amount specified in s. 885.235 (1g) (d).

AB64-SA6,21 Section 21. 103.503 (3) (a) 2. of the statutes is amended to read:

AB64-SA6,42,20 103.503 (3) (a) 2. A requirement that employees performing the work described in s. 66.0903 (4), 2013 stats., or s. 16.856 103.49 (2m) on a project of public works or performing work on a public utility project submit to random, reasonable suspicion, and post-accident drug and alcohol testing and to drug and alcohol testing before commencing work on the project, except that testing of an employee before commencing work on a project is not required if the employee has been participating in a random testing program during the 90 days preceding the date on which the employee commenced work on the project.

AB64-SA6,22 Section 22. 104.001 (3) of the statutes is renumbered 104.001 (3) (intro.) and amended to read:

AB64-SA6,42,23 104.001 (3) (intro.) This section does not affect an any of the following:

AB64-SA6,43,3 (b) An ordinance that, subject to s. 66.0903, requires an employee of a county, city, village, or town, an employee who performs work under a contract for the provision of services to a county, city, village, or town, or an employee who performs work that is funded by financial assistance from a county, city, village, or town, to be paid at a minimum wage rate specified in the ordinance.

AB64-SA6,23 Section 23. 104.001 (3) (a) of the statutes is created to read:

AB64-SA6,43,7 104.001 (3) (a) The requirement that employees employed on a public works project contracted for by a city, village, town, or county be paid at the prevailing wage rate, as defined in s. 66.0903 (1) (g), as required under s. 66.0903.

AB64-SA6,24 Section 24. 106.04 (1) of the statutes is amended to read:

AB64-SA6,43,11 106.04 (1) Definition. In this section, “project" means a project of public works that is subject to s. 16.856 or 84.062 103.49 or 103.50 in which work is performed by employees employed in trades that are apprenticeable under this subchapter.

AB64-SA6,25 Section 25. 109.09 (1) of the statutes is amended to read:

AB64-SA6,44,9 109.09 (1) The department shall investigate and attempt equitably to adjust controversies between employers and employees as to alleged wage claims. The department may receive and investigate any wage claim that is filed with the department, or received by the department under s. 109.10 (4), no later than 2 years after the date the wages are due. The department may, after receiving a wage claim, investigate any wages due from the employer against whom the claim is filed to any employee during the period commencing 2 years before the date the claim is filed. The department shall enforce this chapter and s. ss. 66.0903, 2013 stats., s. 103.49, 2013 stats., and s. 229.8275, 2013 stats., and ss. 16.856, 103.02, 103.49, 103.82, and 104.12, and 229.8275. In pursuance of this duty, the department may sue the employer on behalf of the employee to collect any wage claim or wage deficiency and ss. 109.03 (6) and 109.11 (2) and (3) shall apply to such actions. Except for actions under s. 109.10, the department may refer such an action to the district attorney of the county in which the violation occurs for prosecution and collection and the district attorney shall commence an action in the circuit court having appropriate jurisdiction. Any number of wage claims or wage deficiencies against the same employer may be joined in a single proceeding, but the court may order separate trials or hearings. In actions that are referred to a district attorney under this subsection, any taxable costs recovered by the district attorney shall be paid into the general fund of the county in which the violation occurs and used by that county to meet its financial responsibility under s. 978.13 (2) (b) for the operation of the office of the district attorney who prosecuted the action.

AB64-SA6,26 Section 26. 111.322 (2m) (a) of the statutes is amended to read:

AB64-SA6,44,14 111.322 (2m) (a) The individual files a complaint or attempts to enforce any right under s. 103.02, 103.10, 103.11, 103.13, 103.28, 103.32, 103.34, 103.455, 103.50, 104.12, 109.03, 109.07, 109.075, 146.997, or 995.55, or ss. 101.58 to 101.599 or 103.64 to 103.82.

AB64-SA6,27 Section 27. 111.322 (2m) (b) of the statutes is amended to read:

AB64-SA6,44,19 111.322 (2m) (b) The individual testifies or assists in any action or proceeding held under or to enforce any right under s. 103.02, 103.10, 103.11, 103.13, 103.28, 103.32, 103.34, 103.50, 103.455, 104.12, 109.03, 109.07, 109.075, 146.997, or 995.55, or ss. 101.58 to 101.599 or 103.64 to 103.82.

AB64-SA6,28 Section 28. 111.322 (2m) (c) of the statutes is amended to read:

AB64-SA6,44,23 111.322 (2m) (c) The individual files a complaint or attempts to enforce a right under s. 16.856 or 84.062 66.0903, 103.49, or 229.8275 or testifies or assists in any action or proceeding under s. 16.856 or 84.062 66.0903, 103.49, or 229.8275.

AB64-SA6,29 Section 29. 227.01 (13) (t) of the statutes is created to read:

AB64-SA6,45,4 227.01 (13) (t) Ascertains and determines prevailing wage rates under ss. 66.0903, 103.49, 103.50, and 229.8275, except that any action or inaction which ascertains and determines prevailing wage rates under ss. 66.0903, 103.49, 103.50, and 229.8275 is subject to judicial review under s. 227.40.

AB64-SA6,30 Section 30. 229.682 (2) of the statutes is created to read:

AB64-SA6,45,7 229.682 (2) Prevailing wage. The construction of a baseball park facility that is financed in whole or in part by a district is subject to s. 66.0903.

AB64-SA6,31 Section 31. 229.8275 of the statutes is created to read:

AB64-SA6,45,14 229.8275 Prevailing wage. A district may not enter into a contract under s. 229.827 with a professional football team, as described in s. 229.823, or a related party that requires the team or related party to acquire and construct or renovate football stadium facilities that are part of any facilities that are leased by the district to the team or to a related party unless the professional football team or related party agrees as follows:

AB64-SA6,45,20 (1) Not to permit any employee working on the football stadium facilities who would be entitled to receive the prevailing wage rate under s. 66.0903 and who would not be required or permitted to work more than the prevailing hours of labor, if the football stadium facilities were a project of public works subject to s. 66.0903, to be paid less than the prevailing wage rate or to be required or permitted to work more than the prevailing hours of labor, except as permitted under s. 66.0903 (4) (a).

AB64-SA6,45,25 (2) To require any contractor, subcontractor, or agent thereof performing work on the football stadium facilities to keep and permit inspection of records in the same manner as a contractor, subcontractor, or agent thereof performing work on a project of public works that is subject to s. 66.0903 is required to keep and permit inspection of records under s. 66.0903 (10).

AB64-SA6,46,7 (3) Otherwise to comply with s. 66.0903 in the same manner as a local governmental unit contracting for the erection, construction, remodeling, repairing, or demolition of a project of public works is required to comply with s. 66.0903 and to require any contractor, subcontractor, or agent thereof performing work on the football stadium facilities to comply with s. 66.0903 in the same manner as a contractor, subcontractor, or agent thereof performing work on a project of public works that is subject to s. 66.0903 is required to comply with s. 66.0903.

AB64-SA6,32 Section 32. 946.15 of the statutes is repealed and recreated to read:

AB64-SA6,46,22 946.15 Public construction contracts at less than full rate. (1) Any employer, or any agent or employee of an employer, who induces any person who seeks to be or is employed pursuant to a public contract, as defined in s. 66.0901 (1) (c), or who seeks to be or is employed on a project on which a prevailing wage rate determination has been issued by the department of workforce development under s. 66.0903 (3), 103.49 (3), 103.50 (3), or 229.8275 (3) to give up, waive, or return any part of the compensation to which that person is entitled under his or her contract of employment or under the prevailing wage rate determination issued by the department, or who reduces the hourly basic rate of pay normally paid to an employee for work on a project on which a prevailing wage rate determination has not been issued under s. 66.0903 (3), 103.49 (3), 103.50 (3), or 229.8275 (3) during a week in which the employee works both on a project on which a prevailing wage rate determination has been issued and on a project on which a prevailing wage rate determination has not been issued, is guilty of a Class I felony.

AB64-SA6,47,10 (2) Any person employed pursuant to a public contract, as defined in s. 66.0901 (1) (c), or employed on a project on which a prevailing wage rate determination has been issued by the department of workforce development under s. 66.0903 (3), 103.49 (3), 103.50 (3), or 229.8275 (3) who gives up, waives, or returns to the employer or agent of the employer any part of the compensation to which the employee is entitled under his or her contract of employment or under the prevailing wage determination issued by the department, or who gives up any part of the compensation to which he or she is normally entitled for work on a project on which a prevailing wage rate determination has not been issued under s. 66.0903 (3), 103.49 (3), 103.50 (3), or 229.8275 (3) during a week in which the person works part-time on a project on which a prevailing wage rate determination has been issued and part-time on a project on which a prevailing wage rate determination has not been issued, is guilty of a Class C misdemeanor.

AB64-SA6,47,19 (3) Any employer or labor organization, or any agent or employee of an employer or labor organization, who induces any person who seeks to be or is employed on a project on which a prevailing wage rate determination has been issued by the department of workforce development under s. 66.0903 (3), 103.49 (3), 103.50 (3), or 229.8275 (3) to permit any part of the wages to which that person is entitled under the prevailing wage rate determination issued by the department or local governmental unit to be deducted from the person's pay is guilty of a Class I felony, unless the deduction would be permitted under 29 CFR 3.5 or 3.6 from a person who is working on a project that is subject to 40 USC 3142.

AB64-SA6,48,2 (4) Any person employed on a project on which a prevailing wage rate determination has been issued by the department of workforce development under s. 66.0903 (3), 103.49 (3), 103.50 (3), or 229.8275 (3) who permits any part of the wages to which that person is entitled under the prevailing wage rate determination issued by the department or local governmental unit to be deducted from his or her pay is guilty of a Class C misdemeanor, unless the deduction would be permitted under 29 CFR 3.5 or 3.6 from a person who is working on a project that is subject to 40 USC 3142.

AB64-SA6,33 Section 33. 978.05 (6) (a) of the statutes is amended to read:

AB64-SA6,48,16 978.05 (6) (a) Institute, commence, or appear in all civil actions or special proceedings under and perform the duties set forth for the district attorney under ch. 980 and ss. 17.14, 30.03 (2), 48.09 (5), 59.55 (1), 59.64 (1), 70.36, 84.062 103.50 (8), 89.08, 103.92 (4), 109.09, 343.305 (9) (a), 806.05, 938.09, 938.18, 938.355 (6) (b) and (6g) (a), 946.86, 946.87, 961.55 (5), 971.14 and 973.075 to 973.077, perform any duties in connection with court proceedings in a court assigned to exercise jurisdiction under chs. 48 and 938 as the judge may request and perform all appropriate duties and appear if the district attorney is designated in specific statutes, including matters within chs. 782, 976 and 979 and ss. 51.81 to 51.85. Nothing in this paragraph limits the authority of the county board to designate, under s. 48.09 (5), that the corporation counsel provide representation as specified in s. 48.09 (5) or to designate, under s. 48.09 (6) or 938.09 (6), the district attorney as an appropriate person to represent the interests of the public under s. 48.14 or 938.14.