200.45(1)(e)
(e) If any person fails to comply with a rule of the district, the district may obtain an injunction under
s. 823.02 or the district may initiate an action for the civil remedies under
s. 283.91 (2) or
(5). If the district acts under
s. 283.91 (2) or
(5), the district may recover the forfeiture in a civil action brought by the commission in the name of the district. Collected forfeitures shall be paid into the district's general fund. The forfeiture is in addition to and does not substitute for any damages recoverable by the commission.
200.45(2)(a)(a) The commission may issue special orders in the name of the district directing compliance with the rules of the district within a specified time. All special orders shall be in writing and shall specifically state the action by the user that is required to comply with the order. Service of any special order may be made in the manner provided for service of a summons under
s. 801.11. The commission may designate commission employees to issue special orders in the name of the district in an emergency to prevent damage to the sewerage system from misuse, injury to employees, interference with the process of sewage treatment or disposal or substantial risk to the public health and welfare. Special orders are effective and enforceable upon service, unless the commission specifies a later effective date in the special order or agrees to a different effective date.
200.45(2)(b)
(b) Any person aggrieved by a special order of the district that directly affects the rights or duties of the person may secure a review of the necessity for and reasonableness of the order by filing with the commission, within 30 days after service of the special order, a verified petition specifying the person's objections to the order or the modification desired in the order. Upon receipt of the petition, the commission shall order a public hearing on the petition and make any further investigations it determines advisable. Insofar as applicable,
ss. 227.44 (6),
(7) and
(8) and
227.45 to
227.48 govern the proceeding. The determination of the commission upon any petition is subject to review in a proceeding, brought within 30 days after service of notice of the final determination, in the circuit court of the county in which the district is located or of the county in which the plaintiff resides. Insofar as applicable,
ss. 227.52 to
227.58 govern any proceeding for judicial review under this paragraph.
200.45(2)(c)
(c) If the commission does not stay compliance and a person fails to comply with a special order of the district within the time specified, or if a person fails to begin in good faith to obey, the person is creating a public nuisance enjoinable under
s. 823.02. The district may also initiate an action for the civil remedies under
s. 283.91 (2) or
(5). If the district acts under
s. 283.91 (2) or
(5), the forfeiture may be recovered by the district in a civil action brought by the commission in the name of the district. Collected forfeitures shall be paid into the district's general fund. The forfeiture is in addition to and does not substitute for any damages recoverable by the commission.
200.45(3)
(3) Special use permits. The commission may issue permits for the special use of the sewerage system to private persons, firms or corporations for the transmission and disposal of any liquid, gaseous or solid waste determined to be not detrimental to the sewerage system, to its employees or to the process of sewage treatment, upon terms and conditions specified by the commission. The commission may prescribe and collect an annual fee not to exceed $500 for any permit for special use. The permit is revocable by the commission summarily for violation of the terms or conditions of the permit. A holder of the permit does not acquire any vested right or privilege by being issued a special use permit under this subsection. Any private person, firm or corporation using the sewerage system without a permit for a use for which a permit may be issued under this subsection, or continuing to use the sewerage system after notice of revocation of the permit, shall forfeit to the district not more than $500 for each violation. The forfeiture may be recovered by the district in a civil action brought by the commission in the name of the district. Collected forfeitures shall be paid into the general fund of the district.
200.45(4)
(4) Hearings; designated representatives. The commission may designate representatives to conduct any hearings required under this section and, except as provided in
s. 227.46 (5), may designate any member or employee of the commission for that purpose. If more than one person is designated, the commission shall specify the presiding officer for the hearing. All testimony or other evidence taken, appearances for and against the matter involved and a summary of the arguments of all parties shall be reported to the commission in the manner the commission prescribes.
200.45(6)
(6) Combined sewer overflow abatement. The commission shall not establish by rule or enforce by special order or other means a duty on the part of any municipality to abate combined sewer overflows.
200.47(1)(1)
General powers of the commission. The commission may enter into contracts, agreements or stipulations necessary to perform its duties and exercise its powers under this subchapter, including contracts to purchase, lease or otherwise obtain the use of all necessary equipment, supplies and labor.
200.47(2)(a)(a) Except as provided in
par. (b), all work done and all purchases of supplies and materials by the commission shall be by contract awarded to the lowest responsible bidder complying with the invitation to bid, if the work or purchase involves an expenditure of $20,000 or more. If the commission decides to proceed with construction of any sewer after plans and specifications for the sewer are completed and approved by the commission and by the department of natural resources under
ch. 281, the commission shall advertise by a class 2 notice under
ch. 985 for construction bids. All contracts and the awarding of contracts are subject to
s. 66.0901.
200.47(2)(b)
(b) The commission may purchase without public advertisement or competitive bidding if the article, appliance, apparatus, material or process to be purchased is patented or made or manufactured by one party only or if damage or threatened damage to the sewerage system creates an emergency in which public health or welfare is endangered.
200.47(2)(c)
(c) The commission shall accept the bid of the person who it finds is the lowest responsible bidder complying with the invitation to bid for the contract unless it rejects all bids or relets the contract.
200.47(2)(cm)1.1. Except as provided under
subd. 4., in determining the lowest responsible bid for any contract awarded prior to December 31, 1993, the commission may evaluate the multiplier effect on state revenues and tax receipts of contract moneys which will be spent in this state under the contract. The commission shall promulgate by rule any condition and evaluation criterion which it applies to a bid evaluated under this subdivision. If the commission accepts a bid evaluated under this subdivision, it shall file with the secretary of the commission a written report detailing the reasons for its acceptance. The secretary shall make the report available for public inspection. The commission shall include in the annual report prepared under
s. 200.27 (9) a summary of all bids accepted after an evaluation under this subdivision.
200.47(2)(cm)2.
2. In determining the lowest responsible bid for any contract awarded under this subsection, the commission may use life-cycle cost estimates as part of any evaluation under this subdivision, including the applicable costs of energy efficiency, acquisition and conversion, money, transportation, warehousing and distribution, training, operation and maintenance and disposition or resale.
200.47(2)(cm)3.
3. The commission shall include in any advertisement for bids which it intends to evaluate under this paragraph notice of the conditions and evaluation criteria which it intends to apply to the bids.
200.47(2)(cm)4.
4. This paragraph does not apply to any contract financed in whole or in part by federal funding if any condition of the funding prohibits acceptance of a bid based on the type of evaluation authorized under this paragraph.
200.47(2)(cm)5.
5. Notwithstanding any other provision of law, this state may not deem any contract awarded by the commission under this paragraph ineligible for funding by this state because the dollar amount of the contract awarded by the commission is higher than the lowest dollar bid received by the commission.
200.47(2)(d)
(d) Notwithstanding
pars. (a) to
(c) and in addition to any rights the commission may have under the provisions of the contract, the commission may amend any contract let under
par. (a) with the agreement of the contractor, upon making the following findings:
200.47(2)(d)1.
1. The proposed amendment results in a reduction of the total contract price.
200.47(2)(d)2.
2. The changes do not substantially change the general scope or purpose of the contract work.
200.47(3)
(3) Bid deposits; contract provisions. 200.47(3)(a)(a) The commission may permit or require a sum of money or a certified check payable to the order of the district or a bond for the benefit of the district to be filed with any bid or proposal as liquidated damages in an amount that, in the judgment of the commission, will protect the district from any loss if the bid is accepted, the contract is awarded to the bidder and the bidder fails to execute a contract in accordance with the terms of the bid.
200.47(3)(b)
(b) Every contract made by the commission shall contain an agreement on the part of the contractor and the contractor's sureties requiring the contractor to pay to the district:
200.47(3)(b)1.
1. Actual damages if the contractor breaches the contract; or
200.47(3)(b)2.
2. Liquidated damages in a definite sum, to be named in the contract, for each day's delay in completing the contract after the time specified for its completion. The daily sum shall be an amount that, in the judgment of the commission, will protect the district from loss and will ensure the prompt completion of the contract.
200.47(3)(c)
(c) The commission may require any construction contract and any other contract specified by the commission's executive director to include a bond, which shall guarantee one of the following:
200.47(3)(c)1.
1. The full performance of the contract by the contractor to the satisfaction of the commission, according to the plans and specifications of the commission.
200.47(3)(c)2.
2. The full payment by the prime contractor of all claims for labor performed and materials furnished or used under the contract.
200.47(4)
(4) Day labor. The commission may use day labor to do any work if the executive director of the district in writing so recommends. All bids or part of a bid for any such work, supplies or materials may be rejected by the commission or may be subsequently relet.
200.47(5)
(5) Worker's compensation. The commission may require that all contracts be let subject to
ch. 102.
200.47 History
History: 1981 c. 282,
391;
1985 a. 29;
1999 a. 9;
1999 a. 150 s.
589 to
591; Stats. 1999 s. 200.47.
200.47 Annotation
This section does not abrogate the applicability of the 1-year statute of limitations applicable to public works contracts under s. 779.14. Frietsh v. Refco, Inc.
56 F.3d 821 (1995).
200.47 Annotation
When a mistake of omission in a bid was not material and was quickly cured, an award to the bidder was proper. Dillingham Construction, Inc. v. Milwaukee Metropolitan Sewerage District,
629 F. Supp. 406 (1986).
200.49
200.49
Minority business development and training program. 200.49(1)(a)
(a) "Minority business" means a sole proprietorship, partnership, limited liability company, joint venture or corporation that is at least 51% owned and controlled by one or more minority group members and that is engaged in construction or construction-related activities.
200.49(2)(a)(a) From the amounts allocated for purposes of this section under
s. 20.866 (2) (to), the district shall fund a development and training program for the purpose of developing the capability of minority businesses to participate in construction and construction-related projects funded under the combined sewer overflow abatement program under
s. 281.63.
200.49(2)(b)
(b) From the amounts allocated for purposes of this section under
s. 20.866 (2) (tc), the district shall fund a development and training program for the purpose of developing the capability of minority businesses to participate in construction and construction-related projects funded under the clean water fund program under
ss. 281.58 and
281.59.
200.49(2)(c)
(c) The district may implement the training programs under
pars. (a) and
(b) directly, or may contract under this section for the implementation of these training programs.
200.49(3)
(3) Request for proposals. The executive director shall request proposals for prime contracts from bondable general contractors or construction contractors that are bona fide independent minority businesses. Each proposal submitted shall include all of the following conditions:
200.49(3)(a)
(a) A goal that at least 25% of the total number of workers in all construction trades employed on the project will be minority group members.
200.49(3)(b)
(b) A subcontracting plan that provides sufficient detail to enable the executive director to determine that the prime contractor has made or will make a good faith effort to award at least 20% of the total contract amount to bona fide independent minority business subcontractors.
200.49(4)
(4) Determinations by executive director. 200.49(4)(a)(a) In determining whether a business is a bona fide minority business, the executive director shall take into consideration all of the following:
200.49(4)(a)1.
1. Whether the ownership and control of the business by minority group members is real, substantial and continuing.
200.49(4)(a)2.
2. Whether the minority owners enjoy the customary incidents of ownership and share the risks and profits to an extent commensurate with their ownership interests.
200.49(4)(a)3.
3. Whether the minority owners possess the power to make major decisions on policy and management and to direct the operations of the business on a day-to-day basis.
200.49(4)(a)4.
4. Whether there is any formal or informal restriction, including any provision of the bylaws, partnership agreement, joint venture agreement or corporate charter of the business, that provides for cumulative voting rights or other method of preventing minority owners from making decisions without the cooperation or vote of any nonminority owner.
200.49(4)(a)5.
5. Whether the securities constituting ownership of a corporation claiming to be a minority business are held directly by minority group members. No security held in trust or by a guardian for a child may be considered to be held directly by a minority group member.
200.49(4)(a)6.
6. Whether the contribution of capital or expertise by a minority owner of the business for the purpose of acquiring an interest in the business is real and substantial. If a contribution consists only of a promise to contribute capital or a note payable to the business or a nonminority owner, or mere participation as an employee of the business, the executive director shall not consider it a real and substantial contribution.
200.49(4)(a)7.
7. Whether nonminority owners of the business are disproportionately responsible for the operation of the business.
200.49(4)(a)8.
8. If the minority owners contract with another person for the management of the business, whether the ultimate power to hire and discharge managers rests with the minority owners or with the person with whom the minority owners contract.
200.49(4)(b)
(b) In determining whether a business is independent, the executive director shall consider all relevant factors, including the date the business was established, the adequacy of its resources for the work it is expected to perform under the contract and the degree to which financial, equipment leasing and other relationships with nonminority businesses vary from customary industry practices. Recognition of a business as a separate entity for a tax or corporate purpose is not necessarily sufficient to prove that a business is independent.
200.49(5)
(5) Award of contract. For each contract to be awarded under this section, the executive director shall select from among all applicants the proposal that best meets the requirements under
sub. (3), taking into consideration the cost of implementing the proposal. The district shall award contracts to the applicants selected by the executive director under this subsection.
200.49(6)
(6) Review and implementation committee. The executive director may establish a committee to assist him or her in all of the following areas:
200.49(6)(a)
(a) Reviewing proposals and selecting the prime contractors to which contracts will be awarded.
200.49(6)(b)
(b) Developing the implementation plan that is required under
sub. (7).
200.49(7)(a)(a) The executive director shall develop a plan for the expeditious implementation of the programs created under this section that does all of the following:
200.49(7)(a)1.
1. Provides for the training of minority group members in construction and construction-related trades and occupations.
200.49(7)(a)2.
2. Provides for management and technical assistance to minority group members in construction and construction-related businesses.
200.49(7)(a)3.
3. Provides other management services necessary to assist minority businesses in developing construction-related capabilities and opportunities for participation in construction projects.
200.49(7)(a)4.
4. Provides for the development of a program that enables minority participation in specific components of contracts awarded for the purpose of developing the technical capabilities of minority businesses.
200.49(7)(b)
(b) The executive director shall submit the plan to the secretary of natural resources for review and comment. The secretary of natural resources shall provide the executive director with comments or recommendations for changes in the plan, if any, within 30 days after the plan is submitted. No contracts may be awarded under
sub. (5) until 30 days after the date the plan is submitted to the secretary of natural resources or until the date the executive director receives the secretary's comments or recommendations, whichever is earlier.
200.51
200.51
Commission employees. 200.51(1)
(1)
General powers of the commission. The commission may appoint or employ professional or technical advisers and experts and other personnel the commission requires for the proper execution of its duties under this subchapter, fix their compensations and remove or discharge the employees at pleasure.
200.51(2)
(2) Fixed period appointments. The commission may appoint or employ highly trained, experienced or skilled employees for fixed periods.
200.51(3)
(3) Indemnity bonds. The commission may require any employee to provide an indemnity bond in an amount the commission finds appropriate for the proper performance of the employee's duties. No law respecting civil service applies to the commission or to the commission's employees.
200.51(4)
(4) Retirement benefits. Any employee of the district hired on or after April 26, 1982, is eligible to participate in any compensation or benefit program in which employees of a sewerage commission of a 1st class city under ss.
62.60 to
62.27, 1979 stats., participated, and such program shall treat the employee as eligible to participate in such program. If an employee of the district is receiving retirement benefits from such a program at the time of employment by the district, such employee is not eligible to participate in the program unless the employee elects to suspend his or her retirement benefit payments during his or her employment by the district.
200.51 History
History: 1981 c. 282,
391;
1985 a. 175;
1999 a. 150 s.
593; Stats. 1999 s. 200.51.
200.53(1)(1)
Annual adoption. Annually on or before September 1, the commission shall adopt a capital budget for the benefit of the district, setting forth the anticipated revenues and expenditures for the ensuing fiscal year.
200.53(2)
(2) Capital transfers. During the budget year the commission may, with the concurrence of two-thirds of its members, transfer amounts from one capital account to another if it finds that the funds are not necessary to meet outstanding obligations payable from the account. Nothing in this subsection impairs, or authorizes the commission to impair, any contractual obligation entered into by the commission or the district.
200.53 History
History: 1981 c. 282,
391;
1999 a. 150 s.
594; Stats. 1999 s. 200.53.
200.55
200.55
Financing. The district may borrow money and issue and execute bonds, notes and other forms of indebtedness and may enter into agreements to secure its indebtedness in the manner specified in
subs. (1) to
(7):
200.55(1)(a)(a) The district may issue bonds, notes or certificates for the purposes provided in
s. 66.0621. Except as provided in
pars. (b) to
(fa), the procedure for issuance of these bonds, notes or certificates is as specified in
s. 66.0621.
200.55(1)(b)
(b) The commission has the powers and duties specified for a board or council in
s. 66.0621. The district has the powers and duties specified for a municipality in
s. 66.0621. If
s. 66.0621 specifies that a board, council or municipality shall act by ordinance, the commission shall act by resolution.
200.55(1)(c)
(c) District bonds issued under
s. 66.0621 (4) (a) shall be executed by the chairperson and secretary of the commission rather than by a chief executive and clerk.
