779.08(3)(3)The person against whom the lien is claimed or other interested party depositing the security shall cause to be served upon the lien claimant a notice of the filing of the undertaking or deposit of other security and, if an undertaking, a copy thereof, which notice shall state where and when the undertaking was filed or the security was deposited.
779.08(4)(4)Any action brought after the furnishing of security or pending at the time of the furnishing thereof in accordance with this section shall proceed as if no security had been furnished, except that after the time within which exceptions may be taken to the security, or pursuant to order of the court upon any exception so taken, the clerk shall satisfy the claim for lien of record and discharge any lis pendens filed, and except that the lien thereupon shall attach to the security and the amount adjudged due in the proceeding for foreclosure thereof shall be satisfied out of the security, and the property described in the lien claim shall thenceforth be entirely free of the lien and shall in no way be involved in subsequent proceedings.
779.08(5)(5)If no action to foreclose the lien is brought within the time specified by s. 779.06 (1), the clerk of circuit court in whose office the undertaking or other security was filed or deposited shall on request, and without notice, return the undertaking or security to the party filing or depositing it.
779.08 HistoryHistory: 1979 c. 32 ss. 57, 92 (9); 1979 c. 176; Stats. 1979 s. 779.08; 2005 a. 204.
779.08 AnnotationBy its plain language, the patent purpose of the release bond is to allow a property owner whose property is the subject of a construction lien or a general contractor, acting on the owner’s behalf, to substitute a bond for the property. Because the effect of the release bond procedure is to free the real property from the effect of the claim and lien and any action brought to foreclose such a lien and because a lien foreclosure action is an in rem proceeding, unless personal judgment can otherwise be rendered against the property owner, the owner of the liened property is entitled to a judgment of dismissal from a lien foreclosure action. Hunzinger Construction Co. v. SCS of Wisconsin, Inc., 2005 WI App 47, 280 Wis. 2d 230, 694 N.W.2d 487, 04-0657.
779.09779.09Foreclosure of lien; procedure; parties. In the foreclosure of liens mentioned in s. 779.01, ch. 846 shall control as far as applicable unless otherwise provided in this subchapter. All persons having filed claims for liens under s. 779.01 may join as plaintiffs, and if any do not join they may be made defendants. All persons having liens subsequent to such lien may be joined as defendants. If any person who is a proper party is not a party to the action the person may, at any time before judgment, be made a defendant, and any person who after the commencement of the action obtains a lien or becomes a purchaser may, at any time before judgment, be made a defendant.
779.09 HistoryHistory: 1973 c. 189 s. 20; Sup. Ct. Order, 67 Wis. 2d 585, 775 (1975); 1975 c. 218; 1979 c. 32 ss. 57, 92 (9); Stats. 1979 s. 779.09.
779.09 AnnotationSection 840.10 (1) (a) imposes the requirement of recording a lis pendens on the plaintiff who files a complaint and on a defendant seeking relief on a counterclaim or a cross-complaint, which contains a legal description of the real estate. A defendant construction lien claimant is not a plaintiff, and no cross-claim is necessary in order for a defendant construction lien claimant to obtain a determination of the amount due it and an order for sale in a lien foreclosure action. There is no logical rationale for imposing the requirements of s. 840.10 (1) (a) on a defendant construction lien claimant because it unnecessarily files a cross-claim seeking relief it is entitled to under ss. 779.09 to 779.11. Carolina Builders Corp. v. Dietzman, 2007 WI App 201, 304 Wis. 2d 773, 739 N.W.2d 53, 06-3180.
779.10779.10Judgment. The judgment shall adjudge the amount due to each claimant who is a party to the action. It shall direct that the interest of the owner in the premises at the commencement of the performing, furnishing, or procuring the labor, services, materials, plans, or specifications for which liens are given and which the owner has since acquired, or so much thereof as is necessary, be sold to satisfy the judgment, and that the proceeds be brought into court with the report of sale to abide the order of the court. If the premises can be sold in parcels without injury to the parties, the court may adjudge that the sale be so made. If the plaintiff fails to establish a lien upon the premises but does establish a right to recover for labor, services, materials, plans, or specifications, the plaintiff may have a judgment against the party liable.
779.10 HistoryHistory: 1979 c. 32 s. 57; 1979 c. 176; Stats. 1979 s. 779.10; 2005 a. 204.
779.11779.11Distribution of proceeds of sale. The several claimants whose liens were established in the action shall be paid without priority among themselves. If the sum realized at the sale under s. 779.10 is insufficient after paying the costs of the action and the costs of making the sale to pay the liens in full they shall be paid proportionally.
779.11 HistoryHistory: 1979 c. 32 ss. 57, 92 (9); 1979 c. 110 s. 60 (12); Stats. 1979 s. 779.11.
779.12779.12Sale; notice and report; deficiency judgment; writ of assistance.
779.12(1)(1)All sales under judgments in accordance with s. 779.10 shall be noticed, conducted and reported in the manner provided for the sale of real estate upon execution and shall be absolute and without redemption. In case such sale is confirmed, the deed given thereon shall be effectual to pass to the purchaser all that interest in the premises which is directed to be sold.
779.12(2)(2)If any deficiency arises upon the sale in the payment of the sums adjudged to be due to any lien claimant, the court, upon confirming the sale, may render judgment for the deficiency if demanded in the pleadings against the defendant legally liable to pay the deficiency. The judgment may be entered in the judgment and lien docket and enforced in the same manner that ordinary judgments are. The purchasers at the sale shall be entitled to a writ of assistance under s. 815.63 to obtain possession of the premises sold.
779.12 HistoryHistory: Sup. Ct. Order, 67 Wis. 2d 585, 775 (1975); 1979 c. 32 ss. 57, 92 (9); Stats. 1979 s. 779.12; 1995 a. 224.
779.13779.13Satisfaction of judgment or lien; correction of errors.
779.13(1)(1)Every lien claimant, or the attorney who executed and filed a claim for lien on the claimant’s behalf, who has received satisfaction or tender of the claim with the costs of any action brought on the claim shall, at the request of any person interested in the premises affected and on payment of the costs of satisfying the same, execute and deliver the necessary satisfaction to the interested person. On filing the satisfaction with the clerk of circuit court, the clerk of circuit court shall enter satisfaction of the claim on the judgment and lien docket. Failure to execute and deliver the satisfaction or to satisfy the lien on the judgment and lien docket shall render the person so refusing liable to pay to the person requiring the satisfaction a sum equal to one-half of the sum claimed in the claim for lien.
779.13(2)(2)Every lien claimant, or the attorney who executed and filed a claim for lien on the claimant’s behalf, who has received from any person interested in the premises described in the claim a written statement that the premises described in the claim are not in fact the premises on which the claimant performed, furnished, or procured the labor, services, materials, plans, or specifications to which the claim relates together with a written demand that the claim be satisfied of record shall, if in fact the statement of such person about the mistaken description is true, promptly satisfy the lien claim of record at the lien claimant’s expense. Failure to satisfy the lien claim of record within a reasonable time, if in fact the statement asserting the mistaken description is true, shall render the person so failing liable to pay to the person demanding the satisfaction a sum equal to one-half of the sum claimed in the claim for lien.
779.13 HistoryHistory: 1979 c. 32 s. 57; 1979 c. 176; Stats. 1979 s. 779.13; 1995 a. 224; 2005 a. 204.
779.135779.135Construction contracts, form of contract. The following provisions in contracts for the improvement of land in this state are void:
779.135(1)(1)Provisions requiring any person entitled to a construction lien to waive his or her right to a construction lien or to a claim against a payment bond before he or she has been paid for the labor, services, materials, plans, or specifications that he or she performed, furnished, or procured.
779.135(2)(2)Provisions making the contract subject to the laws of another state or requiring that any litigation, arbitration or other dispute resolution process on the contract occur in another state.
779.135(3)(3)Provisions making a payment to a prime contractor from any person who does not have a contractual agreement with the subcontractor, supplier, or service provider a condition precedent to a prime contractor’s payment to a subcontractor, supplier, or service provider. This subsection does not prohibit contract provisions that may delay a payment to a subcontractor until the prime contractor receives payment from any person who does not have a contractual agreement with the subcontractor, supplier, or service provider.
779.135 HistoryHistory: 1993 a. 213 ss. 164, 165; Stats. 1993 s. 779.135; 2005 a. 204.
779.135 AnnotationSub. (1) voids a contract provision that requires a subcontractor to waive its right to a construction lien before it can get paid. Section 779.05 (1) specifically allows a subcontractor who has signed a contract containing a lien waiver provision to refuse to furnish the waiver unless paid in full for the work or material to which the waiver relates. Thus, a subcontractor facing a void construction lien waiver contract provision has a choice: it can either tender a lien waiver prior to being paid or refuse to do so until it is paid. Tri-State Mechanical, Inc. v. Northland College, 2004 WI App 100, 273 Wis. 2d 471, 681 N.W.2d 302, 03-2182.
779.135 AnnotationA contractual forum selection clause requiring litigation in another state contravened sub. (2) and was void. McCloud Construction, Inc. v. Home Depot USA, Inc., 149 F. Supp. 2d 695 (2001).
779.14779.14Public works, form of contract, bond, remedy.
779.14(1)(1)Definition. In this section, “subcontractor, supplier, or service provider” means the following:
779.14(1)(a)(a) Any person who has a direct contractual relationship, expressed or implied, with the prime contractor or with any subcontractor of the prime contractor to perform, furnish, or procure labor, services, materials, plans, or specifications, except as provided in par. (b).
779.14(1)(b)(b) With respect to contracts entered into under s. 84.06 (2) for highway improvements, any person who has a direct contractual relationship, expressed or implied, with the prime contractor to perform, furnish, or procure labor, services, materials, plans, or specifications.
779.14(1e)(1e)Contract requirements regarding duties of prime contractor.
779.14(1e)(a)(a) All contracts involving $10,000 or more for performing, furnishing, or procuring labor, services, materials, plans, or specifications, when the same pertains to any public improvement or public work shall contain a provision for the payment by the prime contractor of all claims for labor, services, materials, plans, or specifications performed, furnished, procured, used, or consumed that pertain to the public improvement or public work.
779.14(1e)(b)(b) All contracts that are in excess of $30,000 and that are for performing, furnishing, or procuring labor, services, materials, plans, or specifications for a public improvement or public work shall contain a provision under which the prime contractor agrees, to the extent practicable, to maintain a list of all subcontractors, suppliers, and service providers performing, furnishing, or procuring labor, services, materials, plans, or specifications under the contract.
779.14(1m)(1m)Payment and performance assurance requirements.
779.14(1m)(c)(c) State contracts. The following requirements apply to contracts with the state for performing, furnishing, or procuring labor, services, materials, plans, or specifications for a public improvement or public work:
779.14(1m)(c)1.1. In the case of a contract with a contract price exceeding $16,000 but not exceeding $148,000:
779.14(1m)(c)1.a.a. The contract shall include a provision which allows the state to make direct payment to subcontractors or to pay the prime contractor with checks that are made payable to the prime contractor and to one or more subcontractors. This subd. 1. a. does not apply to any contract entered into by the state under authority granted under chs. 84, 85 and 86. This subd. 1. a. also does not apply to any contract with a town, city, village, county or school district for the construction, improvement, extension, repair, replacement or removal of a transportation facility, as defined under s. 84.185 (1) (d); bikeway, as defined under s. 84.60 (1) (a); bridge; parking lot or airport facility.
779.14(1m)(c)1.b.b. The contract shall comply with written standards established by the department of administration. Written standards established under this subd. 1. b. shall include criteria for determining whether the contract requires payment or performance assurances and, if so, what payment or performance assurances are required.
779.14(1m)(c)2.2. In the case of a contract with a contract price exceeding $148,000 but not exceeding $369,000:
779.14(1m)(c)2.a.a. The contract shall include a provision which allows the state to make direct payment to subcontractors or to pay the prime contractor with checks that are made payable to the prime contractor and to one or more subcontractors. This subd. 2. a. does not apply to any contract entered into by the state under authority granted under chs. 84, 85 and 86. This subd. 2. a. also does not apply to any contract with a town, city, village, county or school district for the construction, improvement, extension, repair, replacement or removal of a transportation facility, as defined under s. 84.185 (1) (d); bikeway, as defined under s. 84.60 (1) (a); bridge; parking lot or airport facility.
779.14(1m)(c)2.b.b. The contract shall require the prime contractor to provide a payment and performance bond meeting the requirements of par. (e), unless the department of administration allows the prime contractor to substitute a different payment assurance for the payment and performance bond. The department of administration may allow a prime contractor to substitute a different payment and performance assurance for the payment and performance bond only after the contract has been awarded and only if the substituted payment and performance assurance is for an amount at least equal to the contract price and is in the form of a bond, an irrevocable letter of credit or an escrow account acceptable to the department of administration. The department of administration shall establish written standards under this subd. 2. b. governing when a different payment and performance assurance may be substituted for a payment and performance bond under par. (e).
779.14(1m)(c)3.3. In the case of a contract with a contract price exceeding $369,000 the contract shall require the prime contractor to obtain a payment and performance bond meeting the requirements under par. (e).
779.14(1m)(d)(d) Local government contracts. The following requirements apply to contracts, other than contracts with the state, for performing, furnishing, or procuring labor, services, materials, plans, or specifications for a public improvement or public work:
779.14(1m)(d)1.1. In the case of a contract with a contract price exceeding $16,000 but not exceeding $74,000:
779.14(1m)(d)1.a.a. The contract shall include a provision which allows the governmental body that is authorized to enter into the contract to make direct payment to subcontractors or to pay the prime contractor with checks that are made payable to the prime contractor and to one or more subcontractors. This subd. 1. a. does not apply to any contract with a town, city, village, county or school district for the construction, improvement, extension, repair, replacement or removal of a transportation facility, as defined under s. 84.185 (1) (d); bikeway, as defined under s. 84.60 (1) (a); bridge; parking lot or airport facility.
779.14(1m)(d)1.b.b. The contract shall comply with written standards established by the public body authorized to enter into the contract. Written standards established under this subd. 1. b. shall include criteria for determining whether the contract requires payment or performance assurances and, if so, what payment or performance assurances are required.
779.14(1m)(d)2.2. In the case of a contract with a contract price exceeding $74,000 but not exceeding $148,000:
779.14(1m)(d)2.a.a. The contract shall include a provision which allows the governmental body that is authorized to enter into the contract to make direct payment to subcontractors or to pay the prime contractor with checks that are made payable to the prime contractor and to one or more subcontractors. This subd. 2. a. does not apply to any contract with a town, city, village, county or school district for the construction, improvement, extension, repair, replacement or removal of a transportation facility, as defined under s. 84.185 (1) (d); bikeway, as defined under s. 84.60 (1) (a); bridge; parking lot or airport facility.
779.14(1m)(d)2.b.b. Except as provided in sub. (4), the contract shall require the prime contractor to provide a payment and performance bond meeting the requirements of par. (e), unless the public body authorized to enter into the contract allows the prime contractor to substitute a different payment assurance for the payment and performance bond. The public body may allow a prime contractor to substitute a different payment and performance assurance for the payment and performance bond only if the substituted payment and performance assurance is for an amount at least equal to the contract price and is in the form of a bond, an irrevocable letter of credit or an escrow account acceptable to the public body. The public body shall establish written standards under this subd. 2. b. governing when a different payment and performance assurance may be substituted for a payment and performance bond under par. (e).
779.14(1m)(d)3.3. Except as provided in sub. (4), in the case of a contract with a contract price exceeding $148,000 the contract shall require the prime contractor to obtain a payment and performance bond meeting the requirements under par. (e).
779.14(1m)(e)(e) Bonding requirements.
779.14(1m)(e)2.2. A bond required under par. (c) or (d) shall carry a penalty of not less than the contract price, and shall be conditioned for all of the following:
779.14(1m)(e)2.a.a. The faithful performance of the contract.
779.14(1m)(e)2.b.b. The payment to every person, including every subcontractor, supplier, or service provider, of all claims that are entitled to payment for labor, services, materials, plans, or specifications performed, furnished, or procured for the purpose of making the public improvement or performing the public work as provided in the contract and sub. (1e) (a).
779.14(1m)(e)3.3. A bond required under par. (c) shall be approved for the state by the state official authorized to enter the contract. A bond required under par. (d) shall be approved for a county by its corporation counsel, for a city by its mayor, for a village by its president, for a town by its chairperson, for a school district by its president and for any other public board or body by the presiding officer thereof.
779.14(1m)(e)4.4. No assignment, modification or change of the contract, change in the work covered thereby or extension of time for the completion of the contract may release the sureties on a bond required under par. (c) or (d).
779.14(1m)(e)5.5. Neither the invitation for bids nor the person having power to approve the prime contractor’s bond may require that a bond required under par. (c) or (d) be furnished by a specified surety company or through a specified agent or broker.
779.14(1m)(f)(f) Direct purchase contracts. Paragraphs (c) and (d) do not apply to a contract for the direct purchase of materials by the state or by a local unit of government.
779.14(2)(2)Actions on a performance and payment bond.
779.14(2)(a)(a) Except as provided in par. (am), no later than one year after the completion of work under the contract, any party in interest, including any subcontractor, supplier, or service provider, may maintain an action in that party’s name against the prime contractor and the sureties upon the bond for the recovery of any damages sustained by reason of any of the following:
779.14(2)(a)1.1. Failure of the prime contractor to comply with the contract.
779.14(2)(a)2.2. Except as provided in subd. 3., failure of the prime contractor or a subcontractor of the prime contractor to comply with a contract, whether express or implied, with a subcontractor, supplier, or service provider for performing, furnishing, or procuring labor, services, materials, plans, or specifications for the purpose of making the public improvement or performing the public work that is the subject of the contract with the governmental entity.
779.14(2)(a)3.3. With respect to contracts entered into under s. 84.06 (2) for highway improvements, failure of the prime contractor to comply with a contract, whether express or implied, with a subcontractor, supplier, or service provider of the prime contractor for performing, furnishing, or procuring labor, services, materials, plans, or specifications for the purpose of making the highway improvement that is the subject of the contract with the governmental entity.
779.14(2)(am)1.1. Except as provided in subd. 2., a subcontractor, supplier, or service provider may maintain an action under par. (a) only if the subcontractor, supplier, or service provider has served a written notice on the prime contractor that the subcontractor, supplier, or service provider has performed, furnished, or procured, or will perform, furnish, or procure labor, services, materials, plans, or specifications to the public work or improvement. The notice must be served no later than 60 days after the date on which the subcontractor, supplier, or service provider first performed, furnished, or procured the labor, services, materials, plans, or specifications.
779.14(2)(am)2.2. A notice under subd. 1. is not required if any of the following applies:
779.14(2)(am)2.a.a. The contract for performing, furnishing, or procuring the labor, services, materials, plans, or specifications does not exceed $5,000.
779.14(2)(am)2.b.b. The action is brought by an employee of the prime contractor, subcontractor, supplier, or service provider.
779.14(2)(am)2.c.c. The subcontractor, supplier, or service provider is listed in the list required to be maintained under sub. (1e) (b) or in a written contract, or in a document appended to a written contract, between a subcontractor, supplier, or service provider and the prime contractor.
779.14(2)(b)(b) If the amount realized on the bond is insufficient to satisfy all claims of the parties in full, it shall be distributed among the parties proportionally.
779.14(3)(3)Actions by a county. In an action by a county upon the bond all persons for whose protection it was given and who make claim thereunder may be joined in the action. The county highway commissioner may take assignments of all demands and claims for labor, services, materials, plans, or specifications and enforce the same in the action for the benefit of the assignors, and the judgment may provide the manner in which the assignors shall be paid.
779.14(4)(4)Bonding exemption. A contract with a local professional football stadium district under subch. IV of ch. 229 is not required under sub. (1m) (d) 2. b. or 3. to include a provision requiring the prime contractor to provide or obtain a payment and performance bond or other payment assurance.
779.14 AnnotationA subcontractor can maintain an action against the prime contractor and the prime contractor’s surety if the claim is brought within one year after completion of work on the principal contract. Honeywell, Inc. v. Aetna Casualty & Surety Co., 52 Wis. 2d 425, 190 N.W.2d 499 (1971).
779.14 AnnotationIn a complaint seeking to foreclose a construction lien on a municipal arena, an allegation that the lessee of the arena was acting as the city’s agent in contracting for improvements to the arena was sufficient to withstand a demurrer. James W. Thomas Construction Co. v. City of Madison, 79 Wis. 2d 345, 255 N.W.2d 551 (1977).
779.14 AnnotationThe liability of a prime contractor for damages to employees of a subcontractor under sub. (2) did not include wage penalties under s. 66.293 (3) [now s. 66.0903 (3)]. Consent to be a named party under s. 66.293 (3) [now s. 66.0903 (3)] may occur after one year when the action is for damages under s. 66.293 [now s. 66.0903] in the name of the plaintiffs and other similarly situated employees and was filed within the one-year time period. Strong v. C.I.R., Inc., 184 Wis. 2d 619, 516 N.W.2d 719 (1994).
779.14 AnnotationA prime contractor is responsible for and must provide a bond in the amount of its own contract, not in the amount of the total of all prime contractors together. Golden Valley Supply Co. v. American Insurance Co., 195 Wis. 2d 866, 537 N.W.2d 58 (Ct. App. 1995), 95-0357.
779.14 AnnotationCompletion of work under a contract under sub. (2) occurs when a contractor has completed the work, not when the work is accepted. Arbor Vitae-Woodruff Joint School District No. 1 v. Gulf Insurance Co., 2002 WI App 24, 250 Wis. 2d 637, 639 N.W.2d 788, 01-0993.
779.14 AnnotationThe deletion of former sub. (1m) (b) 1., 1995 stats., which specifically required a municipality to require a prime contractor to furnish a bond, did not eliminate municipal liability in the event the municipality fails to ensure the existence of a contractor’s bond. Holmen Concrete Products Co. v. Hardy Construction Co., 2004 WI App 165, 276 Wis. 2d 126, 686 N.W.2d 705, 03-3335.
779.15779.15Public improvements; lien on money, bonds, or warrants due the prime contractor; duty of officials.
779.15(1)(1)Any person who performs, furnishes, procures, manages, supervises, or administers any labor, services, materials, plans, or specifications used or consumed in making public improvements or performing public work, to any prime contractor, except in cities of the 1st class, shall have a lien on the money or bonds or warrants due or to become due the prime contractor therefor, if the lienor, before payment is made to the prime contractor, serves a written notice of the claim on the debtor state, county, town, or municipality. The debtor shall withhold a sufficient amount to pay the claim and, when it is admitted by the prime contractor or established under sub. (3), shall pay the claim and charge it to the prime contractor. Any officer violating the duty hereby imposed shall be liable on his or her official bond to the claimant for the damages resulting from the violation. There shall be no preference between the lienors serving the notices.
779.15(2)(2)Service of the notice under sub. (1) shall be made upon the clerk of the municipality or in the clerk’s absence upon the treasurer. If any of the money due the prime contractor is payable by the state, service of the notice under sub. (1) shall be served upon the state department, board, or commission having jurisdiction over the work. A copy of the notice shall be served concurrently upon the prime contractor.
779.15(3)(3)If a valid lien exists under sub. (1) and the prime contractor does not dispute the claim within 30 days after service on the prime contractor of the notice provided in sub. (2), by serving written notice on the debtor state, county, town, or municipality and the lien claimant, the amount claimed shall be paid over to the claimant on demand and charged to the prime contractor pursuant to sub. (1). If the prime contractor disputes the claim, the right to a lien and to the moneys in question shall be determined in an action brought by the claimant or the prime contractor. If the action is not brought within 3 months from the time the notice required by sub. (1) is served, and notice of bringing the action filed with the officer with whom the claim is filed, the lien rights are barred.
779.15(4)(4)
779.15(4)(a)(a) When the total of the lien claims exceeds the sum due the prime contractor and where the prime contractor has not disputed the amounts of the claims filed, the debtor state, county, town or municipality, through the officer, board, department or commission with whom the claims are filed, shall determine on a proportional basis who is entitled to the money and shall notify all claimants and the prime contractor in writing of the determination. Unless an action is commenced by a claimant or by the prime contractor within 20 days after the mailing of the notice, the money shall be paid out in accordance with the determination and the liability of the state, county, town or municipality to any lien claimant shall cease.
779.15(4)(b)(b) If an action is commenced, all claimants shall be made parties and the action shall be commenced within 3 months after acceptance of the work by the proper public authority except as otherwise herein provided.
779.15(4)(c)(c) Within 10 days after the filing of a certified copy of judgment in any such action with the officers with whom the notice authorized by sub. (1) is filed, the money due the prime contractor shall be paid to the clerk of court to be distributed in accordance with the judgment.
779.15 HistoryHistory: 1975 c. 147 s. 54; 1975 c. 199, 224, 422; 1979 c. 32 s. 57; 1979 c. 176; Stats. 1979 s. 779.15; 1997 a. 39; 2005 a. 204.
Loading...
Loading...
2021-22 Wisconsin Statutes updated through 2023 Wis. Act 272 and through all Supreme Court and Controlled Substances Board Orders filed before and in effect on October 4, 2024. Published and certified under s. 35.18. Changes effective after October 4, 2024, are designated by NOTES. (Published 10-4-24)