779.03(2) (2)Payment bond may eliminate lien rights. In any case where the prime contractor, pursuant to agreement with the owner, has furnished a payment bond under s. 779.035, all liens provided by s. 779.01 except those of any prime contractor do not exist, ss. 779.02 (1) to (4) and (6) and 779.06 do not apply and all claimants who have no lien shall follow the requirements and procedures specified in ss. 779.035 and 779.036.
779.03 History History: 1973 c. 230; 1979 c. 32 ss. 57, 92 (9); Stats. 1979 s. 779.03; 1993 a. 486; 2005 a. 204.
779.035 779.035 Form of contract; payment bond; remedy.
779.035(1)(1)To eliminate lien rights as provided in s. 779.03 (2), the contract between the owner and the prime contractor for the construction of the improvement shall contain a provision for the payment by the prime contractor of all claims for labor, services, materials, plans, or specifications performed, furnished, procured, used, or consumed, except plans or specifications furnished by the architect, professional engineer or surveyor employed by the owner, in making such improvement and performing the work of improvement. The contract shall not be effective to eliminate lien rights unless the prime contractor gives a bond issued by a surety company licensed to do business in this state. The bond shall carry a penalty for unpaid claims of not less than the contract price, and shall be conditioned for the payment to every person entitled thereto of all the claims for labor, services, materials, plans, and specifications performed, furnished, or procured under the contract and subsequent amendments thereto, to be used or consumed in making the improvement or performing the work of improvement as provided in the contract and subsequent amendments thereto. The bond shall be approved by the owner and by any mortgage lender furnishing funds for the construction of the improvement. No assignment, modification or change in the contract, or change in the work covered thereby, or any extension of time for completion of the contract shall release the sureties on the bond.
779.035(2) (2)
779.035(2)(a)(a) Except as provided in par. (b), any party in interest may, not later than one year after the completion of the contract for the construction of the improvement, maintain an action in his or her own name against the prime contractor and the sureties upon the bond for the recovery of any damages sustained by reason of the failure of the prime contractor to comply with the contract or with the contract between the prime contractor and subcontractors. If the amount realized on the bond is insufficient to satisfy all of the claims of the parties in full, it shall be distributed among the parties proportionally.
779.035(2)(b)1.1. Except as provided in subd. 2., a subcontractor, supplier, or service provider may maintain an action under par. (a) only if the subcontractor, supplier, or service provider has notified the prime contractor in writing that the subcontractor, supplier, or service provider was performing, furnishing, or procuring labor, services, materials, plans, or specifications for the construction of the improvement. The notice must be provided no later than 60 days after the date on which the subcontractor, supplier, or service provider first performed, furnished, or procured the labor, services, materials, plans, or specifications.
779.035(2)(b)2. 2. A notice under subd. 1. is not required if any of the following applies:
779.035(2)(b)2.a. a. The contract for performing, furnishing, or procuring the labor, services, materials, plans, or specifications does not exceed $5,000.
779.035(2)(b)2.b. b. The action is brought by an employee of the prime contractor, the subcontractor or the supplier.
779.035(2)(b)2.c. c. The subcontractor, supplier, or service provider is listed in a written contract, or in a document appended to a written contract, between a subcontractor, supplier, or service provider and the prime contractor.
779.035(3) (3)In any case in which the improvement contract and bond have been prepared and executed pursuant to sub. (1) upon inquiry by any subcontractor, supplier, service provider, laborer, or mechanic performing, furnishing, or procuring labor, services, materials, plans, or specifications for said improvement, the prime contractor and the owner shall so advise the person making the inquiry and shall give the person reasonable opportunity to inspect and examine the contract and bond.
779.035 History History: 1973 c. 230; 1979 c. 32 ss. 57, 92 (9); 1979 c. 110 s. 60 (12); 1979 c. 176; Stats. 1979 s. 779.035; 1991 a. 200; 1993 a. 213; 1995 a. 395; 2005 a. 204.
779.035 Annotation A provision in a contractor's payment bond requiring a supplier of a subcontractor to provide notice to the prime contractor within 90 days after supplying materials in order to secure his rights under the payment bond was not inconsistent with the one-year statute of limitations provided by sub. (2), which was also incorporated into the agreement, and hence was not contrary to public policy. R.C. Mahon Co. v. Hedrich Construction Co. 69 Wis. 2d 456, 230 N.W.2d 621 (1975).
779.035 Annotation The liability of a prime contractor for damages to employees of a subcontractor under s. 779.14 (2) did not include wage penalties under s. 66.293 [now s. 66.0903] (3). Consent to be a named a party under s. 66.293 (3) may occur after one year when the action is for damages under s. 66.293 in the name of the plaintiffs and other similarly situated employees and was filed within the one-year time period. Strong v. C.I.R., Inc. 184 Wis. 2d 619, 516 N.W.2d 719 (1994).
779.036 779.036 Contracts with payment bond; lien; notice; duty of owner and lender.
779.036(1)(1)In any case in which an improvement is constructed or to be constructed pursuant to a contract and payment bond under s. 779.035, any person performing, furnishing, or procuring labor, services, materials, plans, or specifications to be used or consumed in making the improvement, to any prime contractor or subcontractor shall have a lien on the money or other payment due or to become due the prime contractor or subcontractor therefor, if the lienor, before payment is made to the prime contractor or subcontractor, serves a written notice of the lienor's claim on the owner or authorized agent and on any mortgage lender furnishing funds for the construction of the improvement. Upon receipt of the notice, the owner and lender shall assure that a sufficient amount is withheld to pay the claim and, when it is admitted or not disputed by the prime contractor or subcontractor involved or established under sub. (3), shall pay the claim and charge it to the prime contractor or subcontractor as appropriate. Any owner or lender violating this duty shall be liable to the claimant for the damages resulting from the violation. There shall be no preference among lienors serving such notices.
779.036(2) (2)A copy of the notice provided in sub. (1) also shall be served by the lienor, within 7 days after service of the notice upon the owner and lender, upon the prime contractor or subcontractor.
779.036(3) (3)If the prime contractor or subcontractor does not dispute the claim by serving written notice on the owner and the lien claimant within 30 days after service of written notice under sub. (2), the amount claimed shall be paid over to the claimant on demand and charged to the prime contractor or subcontractor pursuant to sub. (1). If the prime contractor or subcontractor disputes the claim, the right to a lien and to the moneys in question shall be determined in an action brought by the claimant or the prime contractor or subcontractor. If the action is not brought within 3 months from the time the notice required by sub. (1) is served, the lien rights under this section are barred.
779.036(4) (4)
779.036(4)(a)(a) When the total lien claims exceed the sum due the prime contractor or subcontractor concerned and where the prime contractor or subcontractor has not disputed the amounts of the claims filed, the owner with the concurrence of the lender shall determine on a proportional basis who is entitled to the amount being withheld and shall serve a written notice of the determination on all claimants and the prime contractor or subcontractor. Unless an action is commenced by a claimant or by the prime contractor or subcontractor within 20 days after the service of said notice, the money shall be paid out in accordance with the determination and the liability of the owner and lender to any claimant shall cease.
779.036(4)(b) (b) If an action is commenced, all claimants, the owner and the lender shall be made parties. Such action shall be brought within 6 months after completion of the work of improvement or within the time limit prescribed by par. (a), whichever is earlier.
779.036(4)(c) (c) Within 10 days after the filing of a certified copy of the judgment in any such action with the owner and lender, the money due the prime contractor or subcontractor shall be paid to the clerk of court to be distributed in accordance with the judgment.
779.036 History History: 1979 c. 32 ss. 57, 92 (9); 1979 c. 110 s. 60 (11); 1979 c. 176; Stats. 1979 s. 779.036; 2005 a. 204.
779.036 Annotation The initial availability to the supplier of a lien under this section on payments made to a subcontractor, did not preclude the bringing of an action on the payment bond since nothing in the statute itself indicates it is to be an exclusive remedy, and the legislative history indicates it was intended as a supplementary remedy to the supplier's rights under the payment bond provided for in s. 779.035. R.C. Mahon Co. v. Hedrich Construction Co. 69 Wis. 2d 456, 230 N.W.2d 621 (1975).
779.036 Annotation A construction lien protects employee benefits in addition to hourly wages. Plumber's Local 458 v. Howard Immel, 151 Wis. 2d 233, 445 N.W.2d 43 (Ct. App. 1989).
779.04 779.04 Claims assignable; notice; prior payment. All claims for liens and right to recover therefor under this subchapter are assignable. Notice in writing of such assignment may be served upon the owner of the property affected and all payments made by the owner before service of such notice shall discharge the debt to the amount paid. The assignee may file petitions for such liens and may bring an action in the assignee's name to enforce the same, subject to the limitations in s. 779.01 (5).
779.04 History History: 1979 c. 32 ss. 57, 92 (9); 1979 c. 176; Stats. 1979 s. 779.04.
779.05 779.05 Waivers of lien.
779.05(1)(1)Any document signed by a lien claimant or potential claimant and purporting to be a waiver of construction lien rights under this subchapter, is valid and binding as a waiver whether or not consideration was paid therefor and whether the document was signed before or after the labor, services, materials, plans, or specifications were performed, furnished, or procured, or contracted for. Any ambiguity in such document shall be construed against the person signing it. Any waiver document shall be deemed to waive all lien rights of the signer for all labor, services, materials, plans, or specifications performed, furnished, or procured, or to be performed, furnished, or procured, by the claimant at any time for the improvement to which the waiver relates, except to the extent that the document specifically and expressly limits the waiver to apply to a particular portion of such labor, services, materials, plans, or specifications. A lien claimant or potential lien claimant of whom a waiver is requested is entitled to refuse to furnish a waiver unless paid in full for the labor, services, materials, plans, or specifications to which the waiver relates. A waiver furnished is a waiver of lien rights only, and not of any contract rights of the claimant otherwise existing.
779.05(2) (2)A promissory note or other evidence of debt given for any lienable claim shall not be deemed a waiver of lien rights unless the note or other instrument is received as payment and expressly declares that receipt thereof is a waiver of lien rights.
779.05 History History: 1979 c. 32 s. 57; Stats. 1979 s. 779.05; 2005 a. 204.
779.05 Annotation Public improvement liens under this section are subject to the waiver provision of s. 289.05 (1) [now s. 779.05 (1)]. Since waiver of a public improvement lien disposes of the lien itself, the refiling of a claim for lien after a waiver was a nullity and the fact that the claim was not disputed following refiling did not revive the lien. Druml Co., Inc. v. New Berlin, 78 Wis. 2d 305, 254 N.W.2d 265 (1977).
779.05 Annotation Section 779.135 (1) voids a contract provision that requires a subcontractor to waive its right to a construction lien before it can get paid. Section 779.05 (1) specifically allows a subcontractor who has signed a contract containing a lien waiver provision to refuse to furnish the waiver unless paid in full for the work or material to which the waiver relates. Thus a subcontractor facing a void construction lien waiver contract provision has a choice: it can either tender a lien waiver prior to being paid or refuse to do so until it is paid. Tri-State Mechanical, Inc. v. Northland College, 2004 WI App 100, 273 Wis. 2d 471, 681 N.W.2d 302, 03-2182.
779.06 779.06 Filing claim and beginning action; notice required before filing; contents of claim document.
779.06(1)(1)No lien under s. 779.01 shall exist and no action to enforce a lien under s. 779.01 shall be maintained unless within 6 months from the date the lien claimant performed, furnished, or procured the last labor, services, materials, plans, or specifications, a claim for the lien is filed in the office of the clerk of circuit court of the county in which the lands affected by the lien lie, and unless within 2 years from the date of filing a claim for lien an action is brought and summons and complaint filed. A lien claimant shall serve a copy of the claim for lien on the owner of the property on which the lien is placed within 30 days after filing the claim. A claim for a lien may be filed and entered in the judgment and lien docket, and action brought, notwithstanding the death of the owner of the property affected by the action or of the person with whom the original contract was made, with like effect as if he or she were then living.
779.06(2) (2)No lien claim may be filed or action brought thereon unless, at least 30 days before timely filing of the lien claim, the lien claimant serves on the owner a written notice of intent to file a lien claim. The notice is required to be given whether or not the claimant has been required to and has given a previous notice pursuant to s. 779.02. Such notice shall briefly describe the nature of the claim, its amount and the land and improvement to which it relates.
779.06(3) (3)Such a claim for lien shall have attached thereto a copy of any notice given in compliance with s. 779.02 and a copy of the notice given in compliance with sub. (2), and shall contain a statement of the contract or demand upon which it is founded, the name of the person against whom the demand is claimed, the name of the claimant and any assignee, the last date of performing, furnishing, or procuring any labor, services, materials, plans, or specifications, a legal description of the property against which the lien is claimed, a statement of the amount claimed and all other material facts in relation thereto. Such claim document shall be signed by the claimant or attorney, need not be verified, and in case of action brought, may be amended, as pleadings are.
779.06 History History: 1979 c. 32 ss. 57, 92 (9); 1979 c. 176; Stats. 1979 s. 779.06; 1995 a. 224; 2005 a. 204.
779.06 Annotation The limitation period under sub. (1) commenced on the date the claimant furnished the last materials for the project, although the claimant supplied 2 succeeding subcontractors and the 2nd subcontractor paid in full. Fredrick Redi-Mix, Inc. v. Thomson, 96 Wis. 2d 715, 292 N.W.2d 528 (1980).
779.06 Annotation When a contractor gave a lien notice to the initial owner when work commenced and had no notice of a subsequent transfer of title, the contractor's lien rights prevailed against subsequent owners who received no lien notice. Wes Podany Const. Co., Inc. v. Nowicki, 120 Wis. 2d 319, 354 N.W.2d 755 (Ct. App. 1984).
779.06 Annotation Sub. (3) does not restrict when amendments to lien claims can be made. It only provides that if an amendment is made after an action is brought, the lien claim may be amended in the same manner as pleadings. Torke/Wirth/Pujara v. Lakeshore Towers, 192 Wis. 2d 481, 531 N.W.2d 419 (Ct. App. 1995).
779.06 Annotation A subcontractor's liens are not protected by incorporation into the prime contractor's lien if the subcontractor makes an independent claim. If the subcontractor brings a lien claim independent from the prime contractor, it is required to follow the procedures required for all claimants under the statutes. Torke/Wirth/Pujara v. Lakeshore Towers, 192 Wis. 2d 481, 531 N.W.2d 419 (Ct. App. 1995).
779.06 Annotation It is settled under Duitman v. Liebelt, 17 Wis. 2d 543, that a contractor has no duty to keep itself updated by searching the title records after construction begins. The critical date, insofar as the lien claimant's duty to check the records in the office of the register of deeds is concerned, is the first date on which the contractor furnishes labor or materials because the right to a lien of a supplier of labor or materials arises on that date. Bayland Buildings, Inc. v. Spirit Master Funding VIII, LLC, 2017 WI App 42, 377 Wis. 2d 149, 900 N.W.2d 94, 16-1807.
779.07 779.07 Judgment and lien docket.
779.07(1)(1)Every clerk of circuit court shall keep a judgment and lien docket in which shall be entered, immediately upon filing, the proper entries under the appropriate headings specified in this subsection, relative to each claim for lien filed, opposite the names of the persons against whom the lien is claimed. The names shall be entered alphabetically. Each page in the judgment and lien docket shall be divided into 9 columns, with headings in the following sequence to the respective columns, as follows:
779.07(1)(a) (a) Name of person against whom lien is claimed.
779.07(1)(b) (b) Name of claimant or assignee.
779.07(1)(c) (c) Attorney for claimant.
779.07(1)(d) (d) Last date of performing, furnishing, or procuring labor, services, materials, plans, or specifications.
779.07(1)(e) (e) Description of copies of notices attached to claim when filed.
779.07(1)(f) (f) Date and time of filing claim.
779.07(1)(g) (g) Description of property.
779.07(1)(h) (h) Amount claimed.
779.07(1)(i) (i) Satisfaction.
779.07(2) (2)The judgment and lien docket shall be presumptive evidence of the correctness of its entries.
779.07 History History: 1979 c. 32 s. 57; Stats. 1979 s. 779.07; 1993 a. 486; 1995 a. 224; 2005 a. 204.
779.08 779.08 Release of lien; undertaking.
779.08(1)(1)The person against whom a lien is claimed or any other interested party may file with the clerk of court in whose office the claim for lien is filed an undertaking executed by a surety to the effect that the person against whom the lien is claimed shall pay the amount of the claim and all costs and damages which may be awarded against that person on account of the lien or in lieu thereof deposit with the clerk of the court a sum of money, certified check or negotiable government bonds in par value equal to 125 percent of the claim for lien. The court in which any action to foreclose the lien may be brought shall determine any question of sufficiency of the surety if exception is taken thereto by the lien claimant within 10 days after notice of the filing of such undertaking or deposit of other security and may upon notice and upon motion of any party, order any sum of money deposited to be invested. The clerk of court shall remove the lien from the judgment and lien docket upon the court's order approving the surety in substitution for the lien. The depositor shall be entitled to any income from the investments, certified check or negotiable U.S. government bonds deposited and the clerk shall pay the income to the depositor without order when received or, in the case of coupons, as the income becomes due.
779.08(2) (2)If an undertaking is furnished, it shall be accompanied by the affidavit of the surety which states that the surety is worth, over and above all debts and liabilities in property within this state not exempt from execution, an amount in the aggregate equal to 125 percent or more of the amount of the claim for lien.
779.08(3) (3)The person against whom the lien is claimed or other interested party depositing the security shall cause to be served upon the lien claimant a notice of the filing of the undertaking or deposit of other security and, if an undertaking, a copy thereof, which notice shall state where and when the undertaking was filed or the security was deposited.
779.08(4) (4)Any action brought after the furnishing of security or pending at the time of the furnishing thereof in accordance with this section shall proceed as if no security had been furnished, except that after the time within which exceptions may be taken to the security, or pursuant to order of the court upon any exception so taken, the clerk shall satisfy the claim for lien of record and discharge any lis pendens filed, and except that the lien thereupon shall attach to the security and the amount adjudged due in the proceeding for foreclosure thereof shall be satisfied out of the security, and the property described in the lien claim shall thenceforth be entirely free of the lien and shall in no way be involved in subsequent proceedings.
779.08(5) (5)If no action to foreclose the lien is brought within the time specified by s. 779.06 (1), the clerk of circuit court in whose office the undertaking or other security was filed or deposited shall on request, and without notice, return the undertaking or security to the party filing or depositing it.
779.08 History History: 1979 c. 32 ss. 57, 92 (9); 1979 c. 176; Stats. 1979 s. 779.08; 2005 a. 204.
779.08 Annotation By its plain language, the patent purpose of the release bond is to allow a property owner whose property is the subject of a construction lien or a general contractor, acting on the owner's behalf, to substitute a bond for the property. Because the effect of the release bond procedure is to free the real property from the effect of the claim and lien and any action brought to foreclose such a lien and because a lien foreclosure action is an in rem proceeding, unless personal judgment can otherwise be rendered against the property owner, the owner of the liened property is entitled to a judgment of dismissal from a lien foreclosure action. Hunzinger Construction v. SCS of Wisconsin, 2005 WI App 47, 280 Wis. 2d 230, 694 N.W.2d 487, 04-0657.
779.09 779.09 Foreclosure of lien; procedure; parties. In the foreclosure of liens mentioned in s. 779.01, ch. 846 shall control as far as applicable unless otherwise provided in this subchapter. All persons having filed claims for liens under s. 779.01 may join as plaintiffs, and if any do not join they may be made defendants. All persons having liens subsequent to such lien may be joined as defendants. If any person who is a proper party is not a party to the action the person may, at any time before judgment, be made a defendant, and any person who after the commencement of the action obtains a lien or becomes a purchaser may, at any time before judgment, be made a defendant.
779.09 History History: 1973 c. 189 s. 20; Sup. Ct. Order, 67 Wis. 2d 585, 775 (1975); 1975 c. 218; 1979 c. 32 ss. 57, 92 (9); Stats. 1979 s. 779.09.
779.09 Annotation Section 840.10 (1) (a) imposes the requirement of recording a lis pendens on the plaintiff who files a complaint and on a defendant seeking relief on a counterclaim or a cross-complaint, which contains a legal description of the real estate. A defendant construction lien claimant is not a plaintiff, and no cross-claim is necessary in order for a defendant construction lien claimant to obtain a determination of the amount due it and an order for sale in a lien foreclosure action. There is no logical rationale for imposing the requirements of s. 840.10 (1) (a) on a defendant construction lien claimant because it unnecessarily files a cross-claim seeking relief it is entitled to under ss. 779.09 to 779.11. Carolina Builders Corporation v. Dietzman, 2007 WI App 201, 304 Wis. 2d 773, 739 N.W.2d 53, 06-3180.
779.10 779.10 Judgment. The judgment shall adjudge the amount due to each claimant who is a party to the action. It shall direct that the interest of the owner in the premises at the commencement of the performing, furnishing, or procuring the labor, services, materials, plans, or specifications for which liens are given and which the owner has since acquired, or so much thereof as is necessary, be sold to satisfy the judgment, and that the proceeds be brought into court with the report of sale to abide the order of the court. If the premises can be sold in parcels without injury to the parties, the court may adjudge that the sale be so made. If the plaintiff fails to establish a lien upon the premises but does establish a right to recover for labor, services, materials, plans, or specifications, the plaintiff may have a judgment against the party liable.
779.10 History History: 1979 c. 32 s. 57; 1979 c. 176; Stats. 1979 s. 779.10; 2005 a. 204.
779.11 779.11 Distribution of proceeds of sale. The several claimants whose liens were established in the action shall be paid without priority among themselves. If the sum realized at the sale under s. 779.10 is insufficient after paying the costs of the action and the costs of making the sale to pay the liens in full they shall be paid proportionally.
779.11 History History: 1979 c. 32 ss. 57, 92 (9); 1979 c. 110 s. 60 (12); Stats. 1979 s. 779.11.
779.12 779.12 Sale; notice and report; deficiency judgment; writ of assistance.
779.12(1)(1)All sales under judgments in accordance with s. 779.10 shall be noticed, conducted and reported in the manner provided for the sale of real estate upon execution and shall be absolute and without redemption. In case such sale is confirmed, the deed given thereon shall be effectual to pass to the purchaser all that interest in the premises which is directed to be sold.
779.12(2) (2)If any deficiency arises upon the sale in the payment of the sums adjudged to be due to any lien claimant, the court, upon confirming the sale, may render judgment for the deficiency if demanded in the pleadings against the defendant legally liable to pay the deficiency. The judgment may be entered in the judgment and lien docket and enforced in the same manner that ordinary judgments are. The purchasers at the sale shall be entitled to a writ of assistance under s. 815.63 to obtain possession of the premises sold.
779.12 History History: Sup. Ct. Order, 67 Wis. 2d 585, 775 (1975); 1979 c. 32 ss. 57, 92 (9); Stats. 1979 s. 779.12; 1995 a. 224.
779.13 779.13 Satisfaction of judgment or lien; correction of errors.
779.13(1)(1)Every lien claimant, or the attorney who executed and filed a claim for lien on the claimant's behalf, who has received satisfaction or tender of the claim with the costs of any action brought on the claim shall, at the request of any person interested in the premises affected and on payment of the costs of satisfying the same, execute and deliver the necessary satisfaction to the interested person. On filing the satisfaction with the clerk of circuit court, the clerk of circuit court shall enter satisfaction of the claim on the judgment and lien docket. Failure to execute and deliver the satisfaction or to satisfy the lien on the judgment and lien docket shall render the person so refusing liable to pay to the person requiring the satisfaction a sum equal to one-half of the sum claimed in the claim for lien.
779.13(2) (2)Every lien claimant, or the attorney who executed and filed a claim for lien on the claimant's behalf, who has received from any person interested in the premises described in the claim a written statement that the premises described in the claim are not in fact the premises on which the claimant performed, furnished, or procured the labor, services, materials, plans, or specifications to which the claim relates together with a written demand that the claim be satisfied of record shall, if in fact the statement of such person about the mistaken description is true, promptly satisfy the lien claim of record at the lien claimant's expense. Failure to satisfy the lien claim of record within a reasonable time, if in fact the statement asserting the mistaken description is true, shall render the person so failing liable to pay to the person demanding the satisfaction a sum equal to one-half of the sum claimed in the claim for lien.
779.13 History History: 1979 c. 32 s. 57; 1979 c. 176; Stats. 1979 s. 779.13; 1995 a. 224; 2005 a. 204.
779.135 779.135 Construction contracts, form of contract. The following provisions in contracts for the improvement of land in this state are void:
779.135(1) (1)Provisions requiring any person entitled to a construction lien to waive his or her right to a construction lien or to a claim against a payment bond before he or she has been paid for the labor, services, materials, plans, or specifications that he or she performed, furnished, or procured.
779.135(2) (2)Provisions making the contract subject to the laws of another state or requiring that any litigation, arbitration or other dispute resolution process on the contract occur in another state.
779.135(3) (3)Provisions making a payment to a prime contractor from any person who does not have a contractual agreement with the subcontractor, supplier, or service provider a condition precedent to a prime contractor's payment to a subcontractor, supplier, or service provider. This subsection does not prohibit contract provisions that may delay a payment to a subcontractor until the prime contractor receives payment from any person who does not have a contractual agreement with the subcontractor, supplier, or service provider.
779.135 History History: 1993 a. 213 ss. 164, 165; Stats. 1993 s. 779.135; 2005 a. 204.
779.135 Annotation Section 779.135 (1) voids a contract provision that requires a subcontractor to waive its right to a construction lien before it can get paid. Section 779.05 (1) specifically allows a subcontractor who has signed a contract containing a lien waiver provision to refuse to furnish the waiver unless paid in full for the work or material to which the waiver relates. Thus a subcontractor facing a void construction lien waiver contract provision with a choice: it can either tender a lien waiver prior to being paid or refuse to do so until it is paid. Tri-State Mechanical, Inc. v. Northland College, 2004 WI App 100, 273 Wis. 2d 471, 681 N.W.2d 302, 03-2182.
779.135 Annotation A contractual forum selection clause requiring litigation in another state contravened sub. (2) and was void. McCloud Construction, Inc. v. Home Depot USA, Inc. 149 F. Supp. 2d 695 (2001).
779.14 779.14 Public works, form of contract, bond, remedy.
Loading...
Loading...
This is an archival version of the Wis. Stats. database for 2017. See Are the Statutes on this Website Official?